With the deepening of legal concept, the legal effect of contract is increasing day by day, and signing a contract is also one of the best ways to avoid disputes. So do you know how to write a legal contract? The following is a sample of stage construction contract I collected for you (5 pieces selected). Welcome to reading. I hope you will like it.
Stage construction contract 1 Party A:
On behalf of:
Party B:
On behalf of:
Through friendly negotiation, Party A and Party B reached an agreement on the anniversary celebration held by Party A on. Both parties agree as follows:
1. Activity time:
2. Venue:
3. Activity theme:
4. The total contract amount signed by Party A and Party B: 13295.00 Yuan only.
Amount in words: thirteen thousand two hundred and ninety-five yuan only.
5. Payment method:
Within three working days after signing the contract, Party A shall pay the contract price in one lump sum.
6. Liability for breach of contract:
Both parties shall abide by the contract, and neither party shall breach the contract at will. In case of breach of contract, 20% of the total contract amount shall be paid to the other party as liquidated damages. If it is really necessary to change the contract, it can only be changed after both parties agree through consultation, otherwise, the other party shall be compensated for the losses caused thereby and bear legal responsibilities.
7. Matters not covered and additional clauses
1) Matters not covered in this contract shall be determined by both parties through consultation and a written agreement shall be signed as an annex to this contract;
2) Additional clauses of this contract are as follows:
8. This contract shall come into effect as of the date of signature (seal) by both parties. This contract is made in duplicate, both of which are equally authentic. Party A and Party B each hold one copy.
Party A (signature and seal):
Party B (signature and seal):
Date:
Stage Construction Contract 2 Party A: (hereinafter referred to as Party A)
Party B: (hereinafter referred to as Party B)
In accordance with the Contract Law of People's Republic of China (PRC) and relevant laws and regulations, and following the principles of equality, voluntariness, fairness and good faith, both parties have entered into this contract on matters related to stage construction and construction project through consultation.
1. Party A entrusts Party B to design and manufacture the stage structure (see the drawings for details):
1. 1, stage address:
1.2. Stage area: length: meter, width: meter, area: square meter;
1.3. Contract price: RMB (in words) only.
1.4. Project content: stage welding, wooden floor laying and first floor carpet decoration.
1.5. The price includes all expenses required by Party B to complete the work agreed in this contract, such as design fees, production fees, materials fees, construction management fees, electricity fees, water fees, transportation fees, handling fees, labor fees, insurance fees and taxes, etc. Party A does not need to pay any other fees to Party B. ..
2. The project cost payment, way:
2. 1. After the contract comes into effect, Party A shall pay Party B 80% of the project price, namely RMB (in words).
2.2. After the stage acceptance, pay 20% of the project cost, namely RMB (in words).
2.3. Payment method: cash and bank remittance.
Three. contract period
3. 1, commencement date _ _ _ _ _ _ _ _
3.2. Completion Date _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _
4. Quality requirements and responsibilities:
4. 1 day to complete all the fabrication and installation of this stage.
4.2 Party B must decorate and decorate in strict accordance with Party A's quality requirements.
Verb (abbreviation of verb) acceptance:
5. 1. For the parts that need to be rectified after acceptance, Party A and Party B shall negotiate and rectify after clarifying their responsibilities until the requirements agreed by both parties are met; All expenses incurred shall be borne by the responsible party.
5.2. Acceptance criteria: The renderings confirmed by both parties shall prevail.
5.3. Party A shall conduct the acceptance according to the quality requirements specified in the contract and the renderings.
Liability for breach of contract of intransitive verbs:
(1) Party A's responsibilities:
1. 1. Party A must pay the project payment on time, otherwise Party B has the right to stop the project at any time, and all the consequences arising therefrom shall be borne by Party A without any responsibility.
1.2. If Party A breaches the contract in the production process, Party B will not refund the advance payment.
1.3. Party A promises to sign a fire protection agreement.
1.4. Party A shall bear the electricity fee at this stage.
(II) Party B's responsibilities:
2. 1. Party B must manufacture and install according to the design drawings, and shall not change the design without authorization.
2.2. Party B must complete the phased construction within the specified time, or bear the corresponding responsibilities.
2.3. The stage built by Party B must be safe and reliable, but it is not caused by Party B's reasons or force majeure. Party B is not responsible for compensation for losses; Before Party A pays off the balance of the project, the ownership of all the goods still belongs to Party B. ..
2.4. The buildings and materials used by Party B must comply with the fire safety regulations.
2.5. During the construction period, Party B shall strictly abide by Technical Regulations for Safety of Construction and Installation Engineering, Safety Operation Regulations for Construction and Installation Workers, People's Republic of China (PRC) Fire Protection Regulations and other relevant laws and regulations.
2.6. Party B is responsible for the safety of the construction site and its construction personnel. In the process of construction and production, Party B shall bear all economic losses caused by accidents such as safety or fire caused by Party B's violation of relevant safety operation regulations and fire control laws.
Seven. This contract shall come into effect as of the date of signature and seal by both parties, and matters not covered in this contract shall be settled by both parties through consultation; If a supplementary agreement is reached, the supplementary agreement has the same legal effect as this contract. If negotiation fails, it shall be under the jurisdiction of the court of Party A's domicile. This contract is made in duplicate, the fax is valid, and each party holds one copy, which has the same legal effect.
Signature of Party A: Signature of Party B:
Seal: seal:
Date:
Party A of the third-stage construction contract:
Address:
Party B:
Address:
Party A will hold the "20xx Top Ten Awards Gala of China's Hardware Industry-Launching Ceremony of 20xx China Hardware Brand Fashion Festival" at Diaoyutai State Guesthouse on xx, xx, and now entrusts Party B to complete the stage and AV construction and other related contracting work. After consultation, both parties signed the following contract.
I. Construction contents:
1. Party B is responsible for the construction and management of contracted projects such as event stage, audio-visual equipment, etc. (see Annex I for the quotation of specific contracted projects);
2. For Party B's contract works and materials, Party B must select raw materials according to the contract provisions and accept Party A's inspection ... If Party B conceals the defects of raw materials or uses raw materials that do not meet the contract requirements, which affects the quality of crops, Party A has the right to request rework and repair.
Second, the quality requirements and technical standards:
Meet the design renderings standards approved by Party A. ..
Three. Time limit for Party B to complete the work and the conditions and time limit for being responsible for the quality:
Party B shall enter the activity site before 6:5438+07:00 pm on xx, xx, xx, and complete the layout, installation and debugging of the above-mentioned venue before 22: 00 pm on XX, XX, XX, and pass the acceptance of Party A. During the official activities and performances, Party B's on-site equipment operators shall handle the above-mentioned stage effects according to Party A's requirements to ensure the smooth progress of meetings and activities.
Four, technical data, drawings to provide methods:
1. Where Party A provides the design scheme, Party A shall submit the confirmed design scheme to Party B months in advance;
2. Party B shall complete the project as scheduled according to the technical specifications and quality required by Party A. If Party A finds that there are quality problems in Party B's work, Party B shall take effective measures to correct them within the notification day of Party A..
Verb (abbreviation of verb) acceptance criteria and time limit:
1. acceptance criteria: as stipulated in the contract and its annexes;
2. Acceptance time: at 22: 00 of the current month, the event will be accepted on site.
VI. Installation and Withdrawal
1. Party A's "activity site" means that the materials are transported to the above-mentioned place designated by Party A. ..
2. Party B shall, on.
7. Settlement method, term and deposit of advance payment.
1, and the total contract price is RMB (including tax). See Annex I for all specific quotation items.
2. Party A shall pay the advance payment to Party B within working days after the signing of the contract. After the project passes the acceptance of Party A, Party A shall pay the balance of 8,000 yuan to Party B on the day of the activity.
3. However, if there are deductions after the activity, Party A shall be responsible for the deductions in cash.
Eight. responsibility for breach of contract
1, Party A's liability for breach of contract
(1) For reasons that cannot be agreed, Party A unilaterally terminates the contract in advance before Party B enters the site for construction, and pays the liquidated damages of the total contract price to Party B; If Party B has started to arrange for Party A to unilaterally terminate the contract in advance, Party A shall pay Party B a penalty of 65,438+000% of the total contract price.
(2) If Party A delays payment, Party A shall pay 0% of the overdue payment amount to Party B as liquidated damages for each overdue day;
(3) If Party A fails to pay the advance payment to Party B on time, Party B has the right to unilaterally terminate the cooperation under this contract. Party B has not breached the contract.
2. Party B's liability for breach of contract:
If Party B changes or terminates the contract without Party A's consent, or Party B fails to complete the contracted project on time and with good quality as stipulated in this contract, Party A has the right to deduct the contract amount of the corresponding project and require Party B to pay a penalty equivalent to 50% of the contract amount.
9. Party B shall bear all risks before delivering the crops or work stipulated in the contract and passing the acceptance of Party A. ..
X. Ways to resolve contract disputes: through consultation; If negotiation fails, it shall be under the jurisdiction of the court where Party A or Party B is located.
XI。 Other terms agreed by both parties.
1. This contract is concluded in accordance with the Contract Law of People's Republic of China (PRC);
2. The payment period of liquidated damages and compensation shall be within 10 days from the date of the observant party's notice;
3. Party B shall be responsible for safety measures and management of contractors according to its responsibilities, and abide by and implement the provisions on safe and civilized contracting;
Twelve. supplementary terms
1. For matters not covered in this contract, both parties shall negotiate and sign a supplementary contract. If the supplementary contract is inconsistent with this contract, the supplementary contract shall prevail.
2. This contract shall come into effect as of the date of signature and/or seal by both parties.
3. The annexes to this contract are an effective part of this contract:
4. This contract and its annexes are made in duplicate, one for each party, with the same legal effect.
All artificially modified parts of the contract are invalid.
Party A: Party B:
Representative: representative:
Signature time:
Entrusting unit of the fourth stage construction contract: _ _ _ _ _ (hereinafter referred to as Party A)
Employer: _ _ _ (hereinafter referred to as Party B)
According to the General Principles of the Civil Law and the relevant local regulations of _ _ _ _ _ _ _ _, both parties reached the following agreement through friendly negotiation on the specific matters that Party A entrusts Party B to be responsible for the construction of _ _ _ _ _ _ _.
I. Overview of the Project
1. Project name: _ _ _ _ _ _ _ booth construction project.
2. Exhibition time: MM DD YY to MM DD YY. Party B must complete the exhibition and deliver it to Party A before _ _ _ _ _ _.
3. Exhibition time: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _.
4. Exhibition address: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _.
5. Booth specifications: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _.
6. Exhibition time: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _
7. Construction content: booth design, production and construction of exhibition venues, as well as exhibition after exhibition and cleaning of exhibition venues according to the requirements of the convention and exhibition center. After the exhibition is withdrawn, all the decorations and materials made and erected will be transported to the place designated by Party A. ..
8. Contracting method: contracting work, contracting materials, contracting quality and contracting time limit.
Second, the contract amount
The amount is RMB _ _ _ _ ten thousand yuan, and the price is a one-time guarantee, which will not be adjusted due to any factors such as the increase of engineering quantity.
The price includes all expenses required by Party B to complete the work agreed in this contract, such as design fee, production fee, material fee, exhibition construction management fee, electricity fee, water fee, transportation fee, loading and unloading fee, exhibition withdrawal fee, labor fee, taxes, etc. In addition, Party A does not need to pay any other fees to Party B. ..
Three. terms of payment
1. For the first time, after the contract is signed, Party A shall pay 40% of the total contract amount to Party B, namely RMB ten thousand Yuan only.
2. For the second time, Party A shall pay Party B 20% of the total contract price, i.e. RMB 10,000 Yuan only, within three days from the date when Party B completes all booth construction and passes the acceptance of Party A. ..
3. For the third time, after Party B dismantled the booth according to Party A's requirements and sent it to the place designated by Party A, Party A paid 40% of the total contract price to Party B, namely RMB Yuan only.
Fourth, the design of the booth.
1. The design drawings and renderings of this project are provided by Party B and come into effect after being signed and confirmed by Party A. Party B shall carry out the construction according to the booth design renderings signed and confirmed by Party A. Without the written consent of Party A, Party B shall not change the booth design renderings confirmed and effective by Party A without authorization;
2. Party B shall be responsible for the contents of its design scheme and renderings, and Party A's review and confirmation shall not be regarded as Party A's responsibility for this. Party B shall ensure that the contents of its design scheme and renderings, including pictures, signs and expressions, are legally obtained, and have the right to use them and use them for booth production.
3. Party B's design shall not infringe the copyright, portrait right and other rights of others. In case of punishment or compensation due to infringement of other people's rights or violation of relevant regulations, Party B shall be liable for compensation and punishment.
Verb (abbreviation of verb) Rights and obligations of Party A.
1. Party A shall sign the corresponding drawings for confirmation before commencement. If there are corresponding changes during the exhibition, Party B shall implement them according to Party A's requirements.
2. During the exhibition, Party A shall actively cooperate with Party B's work and provide the required relevant materials.
3. If Party A requests to increase the workload beyond the contract, it shall pay extra fees to Party B, but Party B shall make an offer to Party A in advance.
4. Party A shall pay in time as stipulated in the contract.
5. After the exhibition, all the non-leased booth building materials removed by Party B belong to Party A, and Party A reserves the right to dispose of them.
The rights and obligations of party b with intransitive verbs
1. Party B shall submit the construction plan and progress to Party A before the exhibition, and implement it after being confirmed by Party A. If Party A raises any objection, Party B shall implement it according to Party A's requirements. However, Party A's examination and confirmation does not mean that Party A is responsible for this.
2. Send _ _ _ _ _ _ _ _ as the representative of Party B on site to be responsible for the performance of the contract. Organize the construction as required, and complete the construction task on time with good quality and quantity. Solve all matters that Party B is responsible for. Any promise, guarantee, letter, signature and confirmation made by the person in charge to Party A shall be regarded as the behavior of Party B, and Party B shall bear the responsibility.
3. Party B shall be responsible for purchasing all materials, facilities and equipment required for construction. Party B shall ensure that all the products it purchases are qualified products, and provide Party A with the product qualification certificate before use. If the products purchased by Party B do not meet the quality requirements or have different specifications, Party B shall bear the responsibilities by itself, and shall be liable for the personal or property losses of Party A and the third party.
4. Strictly implement the construction specifications, safety operation procedures, fire safety regulations and environmental protection regulations. Carry out the construction in strict accordance with the drawings.
5. Abide by the regulations of the state or local government and relevant departments on the management of the construction site, and do a good job in the safety, garbage removal and disposal of the construction site.
6. Party B shall ensure that the project can meet the requirements of engineering design drawings and renderings.
7. After the booth construction is completed, Party A shall check and accept the appearance quality of the booth project, which shall not exempt Party B from the responsibilities due to the inherent quality problems or other quality defects of the project. Party B must be responsible for the quality of the project. After the completion of the project, if Party A or any third party suffers losses due to the quality problems of the project, Party B shall be liable for compensation.
8. During the production, construction and exhibition of the booth, Party B must be responsible for the safety of the booth and pay attention to the coordination with other construction units and exhibitors in the exhibition area. In case of property or personal injury of Party A or any third party due to safety accidents such as the collapse and fall of the booth, Party B shall bear the responsibility. ..
9. Be responsible for the protection, storage and maintenance of all facilities (including equipment provided by Party A and furniture stacked on site) and finished products of the project before the exhibition is closed, and Party B shall be responsible for the losses caused thereby.
10. After the exhibition, Party B shall dismantle the booth according to the time required by Party A, and deliver the dismantled booth materials to the place designated by Party A free of charge. Party B shall ensure the safety of Party A's property during the exhibition withdrawal and compensate for any losses.
Seven. Safety and fire protection agreement
1. During the construction period, Party B shall strictly abide by the Technical Regulations for Safety of Construction and Installation Works, the Rules for Safe Operation of Construction and Installation Workers, the People's Republic of China (PRC) Fire Protection Regulations and other relevant laws and regulations.
2. Party B is responsible for the safety of the construction site and its construction personnel. If Party B violates the relevant safety operation rules and fire regulations during the construction and production process, resulting in safety or fire accidents and other liability accidents, Party B shall bear all the economic losses caused thereby.
Eight. responsibility for breach of contract
1. Due to the particularity of the project, Party B must ensure that the project can be delivered on time. If Party B fails to enter the exhibition site, complete the exhibition or perform any other obligations, Party B shall bear a penalty of 0.5 ‰ of the total contract price for each hour overdue, and Party A has the right to terminate this contract if it is overdue for 8 hours.
2. If the booth made by Party B does not conform to the agreement or has quality problems, Party B shall be responsible for rework or rework. If the construction period is delayed, Party B shall also be liable for breach of contract. If Party A refuses to make corrections, fails to make corrections within the time limit or fails to meet the agreement after one correction, Party A has the right to terminate this contract.
3. If Party B violates other agreements in this contract and is notified by Party A to make corrections within a time limit, Party A has the right to terminate this contract if it fails to make corrections within the time limit.
4. If this contract is dissolved due to Party B's breach of contract, Party B shall not only compensate all losses caused to Party A, but also bear 30% of the total contract price as liquidated damages, and the payment made by Party A shall be returned to Party A. ..
Nine. Disputes or handling of disputes In case of disputes during the performance of this contract, both parties shall settle them through consultation; If negotiation fails, it shall be submitted to the people's court where Party A is located for litigation.
X for matters not covered in this contract, both parties may sign a supplementary agreement, which has the same legal effect as this contract.
XI。 This Contract is signed on _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _
Party A (seal): _ _ _ _ _ Party B (seal): _ _ _ _ _ _
Representative of Party A (signature): _ _ _ Representative of Party B (signature): _ _ _ _
_ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _
Stage Construction Contract 5 Party A:
Party B:
Party A and Party B have reached the following agreement on Party B's production and installation of Party A's booth in XXX in accordance with the relevant laws and regulations and on the principle of equality, mutual benefit, honesty and trustworthiness:
I. Overview of the Project:
1, project name:
2. Project area and specifications:
3. Project address:
4. Opening hours:
Two. Contract amount (type, RMB) and payment method:
1. Total project cost (in words): RMB XXX, including site management fee, electricity fee and invoice tax.
2. Within 3 working days after the signing of the contract, Party A shall prepay XXX of the total project amount to Party B as the advance payment for the project, namely XXX. After the booth is made and accepted by Party A, and Party A participates in the exhibition, Party B shall pay the final payment of RMB XXX in one lump sum within three working days.
Third, the construction period:
After the contract is signed, Party B shall make it according to the design scheme and designated materials determined by both parties, and shall not modify the scheme without authorization, and must complete the erection and decoration work within XXX days and pass the acceptance of Party A, so as to ensure that Party A can participate in the exhibition on time within XXX days.
Fourth, the project acceptance
After the drawings designed by Party B for Party A are finalized by Party A, Party B will carry out construction lofting in strict accordance with the finalized design scheme and dimensions. After finalization, Party A will propose the design change fee, which shall be borne by Party A. Party A shall issue an acceptance certificate. (There are some natural differences between the effect drawing and the actual effect) If Party A fails to accept the project at that time, the project will be deemed as qualified.
Terms of service of intransitive verbs:
1. Party B is responsible for installation and all lighting and debugging on site.
2. During the exhibition, Party B will assign 1-2 people to be responsible for the sanitary maintenance and safety of the booth. Once there is any bad situation, the on-site maintenance personnel will solve it in the shortest time.
3. Under the condition that the overall plan remains unchanged, Party A requires reasonable modification, and Party B shall cooperate.
4. Party B shall set up and arrange the booth in strict accordance with the final design scheme.
5. Under the condition that the overall plan remains unchanged, Party A requires reasonable modification, and Party B shall cooperate in time.
6. Party B promises to dismantle the booth within the specified time after the cancellation of the exhibition, and clean it up and transport it out of the exhibition hall. The right to take back the booth belongs to Party B. ..
Seven. Liability for breach of contract:
This contract has legal effect once it is signed, and Party A and Party B shall not unilaterally terminate the contract. Any party who proposes to terminate the contract shall be regarded as breach of contract and pay all economic losses to the observant party; If the project cannot be carried out smoothly because Party A's project payment is not in place, Party B will not bear the relevant responsibilities arising therefrom; If Party B fails to perform the service items stipulated in this contract as scheduled due to Party B's reasons, which affects Party A's participation in the exhibition, Party B shall compensate Party A for the corresponding losses. If the project is delayed due to force majeure, Party A and Party B shall settle it through negotiation.
Eight. This contract is made in duplicate, one for each party, and shall come into effect as of the date of signature. The faxed copy has the same legal effect.
Nine. Matters not covered in this contract shall be settled by both parties through consultation.
Party A:
Party B:
Date:
;