With the general improvement of people's legal awareness, more and more things need to use contracts, and signing contracts can clarify the rights and obligations of both parties. Then do you know how to write a formal contract? The following is a simple contract model (6 copies in general) for Shanghai house decoration, which I compiled for you, for your reference, hoping to help friends in need.
Shanghai Simple House Decoration Contract 1: (hereinafter referred to as Party A)
Contractor: (hereinafter referred to as Party B)
According to the Economic Contract Law of the People's Republic of China, the Regulations on Construction and Installation Project Contracts and the relevant regulations of the local government, the rights, obligations and economic responsibilities of both parties are defined through consultation between Party A and Party B. In order to ensure the smooth completion of the exterior wall decoration project of Party A's office building, both parties have reached the following contract terms:
Chapter I Project Overview
Article 1: Project Overview
1, project name: exterior wall decoration project of office building of xx Co., Ltd.
2. Project location:
3. Contracting method: This project is contracted by contracting with labor and materials.
4. Scope of contract:
(1) Clean the external wall of the office building, and scrape the seams and uneven places with 107 glue and black cement slurry; (2) The external wall of the office building is scraped with 107 glue and Danish white cement; (3) Dismantling bamboo scaffolding and using automatic lifting hanging basket for construction; (4) Fully coating alkali-resistant primer; 5] Spray the stone paint twice with the color specified by Party A, and divide it according to the manufacturer's regulations; [6] Spray color-preserving waterproof topcoat twice.
Chapter II Construction Period
Article 2: According to the actual workload of the project, the total construction period is 30 days, and the commencement and completion dates of the project are as follows:
Commencement date: 10, XX 10.
Completion date: XX year 165438+ 10/0.
Article 3: In the course of construction, the construction period may be extended under the following circumstances:
1. Stop work due to irresistible natural disasters, and postpone construction due to major changes of Party A. ..
2. Due to policy changes and irresistible reasons of Party A and Party B, the project construction is stopped or postponed, which makes it impossible to continue to perform the contract or some items and contents in the contract.
3. Other circumstances agreed by Party A. ..
Article 4: The extension of the construction period shall take effect after timely negotiation and signature by both parties.
Chapter III Responsibilities of Both Parties
Article 5: Party A's responsibilities
1, with road, water and electricity construction conditions before construction; Provide Party B with construction drawings.
2. Party B shall be provided with the information of the structure and pipeline of the office building and the information of the adjacent buildings.
Article 6: Party B shall perform the following obligations and responsibilities
1. Strengthen the management of personnel on the construction site and abide by the management regulations of Party A's office building. Party B shall bear the economic losses caused by violation of regulations.
2. Party B shall be responsible for the construction water and domestic electricity consumption of construction personnel, which shall be measured by hanging meter and delivered at the specified water and electricity price.
3. Take active measures to protect pipelines and adjacent buildings, structures, roads and trees on the construction site. If there is any damage, Party B shall be responsible for compensation.
Chapter IV Engineering Quality
Article 7: Party B shall organize the construction in strict accordance with the standards, specifications and design requirements, accept the inspection by Party A and the quality supervision department at any time, and provide convenient conditions for the inspection.
1. The quality requirements of this project meet the current national quality acceptance standards for building decoration and decoration projects.
2. If serious irrationality is found during the construction, Party B shall explain the reasons and reasons in detail in written form, Party A shall put forward suggestions for modification or change, and both parties shall start the construction after signing the modification documents.
Chapter V Material Supply
Article 8: Party B shall be responsible for purchasing the required materials. The materials purchased by Party B must have factory certificate and material inspection report, which can only be used after being approved by Party A, and Party B shall be fully responsible for any violation.
Article 9: If the materials purchased by Party B fail to pass the acceptance of Party A, Party B shall unconditionally return the materials to the site, and all losses caused thereby shall be borne by Party B, and the liabilities for breach of contract shall be investigated.
Chapter VI Contract Price and Settlement
Article 10: Basis of Project Settlement
According to Party A's requirements and on-site visa, after the project is completed, the final statement of the project submitted by Party B will be settled by Anhui Dida Engineering Pipeline Co., Ltd.
Article 11: The project cost shall be determined by Party A and Party B, with 48 yuan per square meter, and shall be settled according to the facts after completion.
After Party B's project is completely completed, Party A shall pay 50% of the total project cost; Pay 30% of the total cost after the project is completed and accepted; The remaining 20% will be paid to Party B in one lump sum after one year without any quality problems.
Chapter VII Completion Acceptance
Article 12: Party B shall complete the project five days before the completion acceptance.
Article 13: Party A shall organize relevant departments to conduct acceptance within 5 days after receiving Party B's completion acceptance report. If Party A fails to organize the acceptance or disapprove the acceptance report without justifiable reasons, it shall be deemed as qualified.
Article 14: The approval date of the completion acceptance report is the completion date.
Chapter VIII Reward and Punishment and Arbitration
Article 15: If the project quality experience is unqualified, Party B shall rework it; If the rework still fails to pass the acceptance, Party A will fine Party B at 65,438+00% of the total price.
Article 16: Party A does not require the project to be completed in advance. If the construction period is delayed due to Party B, Party A will fine Party B 300 yuan for each delay of 1 day.
Article 17: In case of any dispute arising from this contract, both parties shall settle it through negotiation in time. If negotiation fails, a lawsuit may be brought to a people's court with jurisdiction.
Chapter IX Other Matters
Article 18: Safe construction: Party B shall take strict safety protection measures according to relevant regulations, and bear the responsibility for accidents and all expenses caused by ineffective safety measures. All expenses arising therefrom shall be borne by the responsible party.
Article 19: Party B shall not subcontract this project. If Party B is found to be in breach of contract, Party A has the right to order Party B to leave immediately and compensate Party A for all losses.
Article 20: This contract shall come into force after being signed by both parties. Matters not covered in this contract shall be discussed separately by both parties. After the project is completed and accepted, except for the relevant clauses, other clauses are terminated.
This contract is made in duplicate, each party holds 1 copy.
Employer: Contractor:
Legal representative:
Authorized representative: authorized representative:
Date:
Shanghai Housing Decoration Simple Contract 2 Party A: ID number:
Party B: ID number:
Party B undertakes the construction of the external wall decoration project of Building () where Party A is located, and both parties reach the following opinions through consultation:
1. Nature of the project: Party B contracts the project and materials (double contracting).
Second, the construction technology: scrape the white cement twice, sand it once, and paint the exterior wall twice (white).
Three, quality requirements: no peeling, no shedding, bright, mid-range exterior paint or above. The warranty period is three years (warranty period).
4. Project cost: RMB 10 per square meter (RMB/square meter), and the project payment is calculated according to the actual completed area.
Verb (abbreviation of verb) payment method: if the project is paid in full after acceptance, the balance will be paid in advance as quality guarantee.
Safety of intransitive verbs: operate according to the construction specifications, and Party B shall bear all safety responsibilities.
Seven, Party A's existing scaffolding, Party B can borrow the construction, and Party B is responsible for checking and strengthening the safety.
8. Time limit: the project task shall be completed within days from the date of commencement.
Nine. This agreement is made in duplicate, one for each party, and shall come into force after being signed.
Party A (official seal): _ _ _ _ Party B (official seal): _ _ _ _ _
Legal representative (signature): _ _ _ _ _ Legal representative (signature): _ _ _ _ _
_ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _
Shanghai Housing Decoration Simple Contract 3 Party A:
Party B:
According to the Construction Law of People's Republic of China (PRC) and other relevant laws and regulations, Party A and Party B follow the principles of equality, voluntariness, fairness, honesty and credibility. Party A agrees to contract the external decoration project of the office building to Party B for construction. In order to clarify the rights and obligations of both parties, the following terms and conditions are reached on related matters through consultation, and both parties are expected to abide by them:
1. Project content: office building exterior wall latex paint.
2. Contracting method: contracting, contracting materials, contracting quality and contracting period.
3. Project unit price: RMB one hundred and sixty-six Yuan only per square meter (16 yuan/㎡).
4. Engineering survey: Calculate the developed area of doors and windows according to the actual developed area, and deduct the area of doors and windows. External scaffolding shall be provided by Party A, and the bedding of scaffolding shall be provided by Party B. ..
Verb (abbreviation of verb) payment method: the project will be paid according to the progress. After the external wall base is processed, 25% of the project cost will be paid after pouring the bottom, 50% of the total project cost will be paid after completion, 20% of the project cost will be paid after acceptance, and the remaining 5% will be paid as warranty money one year later.
Duration of the intransitive verb contract: the construction date is days. Completed from year month day to year month day.
7. Project quality: according to the current national standards for the completion and acceptance of relevant projects. The quality level is not less than qualified. The materials used must meet the quality requirements of qualified products, the colors and patterns meet the design requirements, and the coating is evenly bonded and firm, without missing coating, undercoating, peeling and powder dropping. Alkali-resistant primer is used for base treatment, and the coating is consistent with other decoration materials, with clear interface and uniform color. The quality is guaranteed for five years.
Eight. Safety: Party B shall pay attention to construction safety during construction. In case of safety accidents caused by inadequate construction safety measures, Party B shall be responsible, and Party A shall not bear any legal responsibilities.
Nine. This agreement shall come into force after being signed and sealed by both parties, and shall become invalid after all the completion acceptance and settlement of the final payment. This agreement is made in duplicate, one for each party. If there are any matters not covered in this agreement, they can be settled through negotiation in a sincere and friendly way.
Party A (official seal): _ _ _ _ Party B (official seal): _ _ _ _ _
Legal representative (signature): _ _ _ _ _ Legal representative (signature): _ _ _ _ _
_ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _
Shanghai Housing Decoration Simple Contract 4 Party A:
Party B:
The exterior wall decoration of Party A's house located in Hongshuitang is contracted by Party B. In order to clarify the responsibilities of both parties, the following contract is hereby concluded and abided by both parties:
I. Obligations of Party A:
1. Party A prepares raw materials for Party B's construction and supplements the required raw materials according to the progress of the project.
2. Party A shall provide Party B with water, electricity and ancillary facilities needed for decoration.
3. Party A lays bamboo rafts for Party B's construction site.
4. Party A is responsible for coordinating various relationships in the construction process.
Two. Scope of construction of Party B
1, leveling wall with external wall powder and coarse sand.
2. Stick cultural bricks and tiles on the external wall according to the drawings.
3. Corrugated tiles or S-shaped tiles should be attached to sloping surfaces and sloping roofs.
4. Mosaic ceiling
5, balcony gourd
Three. Obligations of Party B
1. Cover with cement, lime, etc. Before work or rain, put away items that are easy to be lost and damaged, and turn off the water and electricity.
2. The proportion of sand meets the quality requirements, saves raw materials, and is used now, leaving no mortar and cement slurry overnight.
3. Pay attention to safe construction and civilized construction. Party B shall be fully responsible for the safety of itself and its employees, and Party A shall not be responsible for it.
Fourth, the project cost:
Paint and paste tiles, mosaics, glazed tiles, etc. And settled in 42 yuan per square meter.
Verb (abbreviation for verb) Terms of payment:
Check out and pay after completion.
Other agreements on intransitive verbs:
1. In case of any change during construction, both parties shall communicate with each other and reach an agreement before construction.
2. Matters not covered in this contract shall be settled by both parties through consultation.
3. This contract is made in duplicate, one for each party, with the same legal effect. Sign by both parties.
Signature of Party A: Signature of Party B:
Date:
Shanghai Housing Decoration Simple Contract 5 Party A:
Party B:
Both parties agree to contract out the external wall decoration project to Party B for the renovation project of Kyoto Haoting Building 9 # ~ 22 # and 23 # ~ 24 # undertaken by Party A.. In order to facilitate the construction management and determine the responsibilities and settlement methods of both parties, the following clauses are formulated for both parties to implement.
I. Responsibility of Party A
1, responsible for providing notices of changes related to construction drawings, projects and projects;
2, responsible for coordinating the use of lifting machinery.
3. Provide relevant materials to be present.
4. Responsible for construction technical disclosure and safety technical disclosure.
Two. Party B's responsibilities
1, in the process of construction, the construction must be carried out in strict accordance with the construction drawings and the current relevant national standards, so as to ensure that it meets the quality acceptance specifications of xx building decoration engineering, and ensure that the tiles constructed by full-paste method are free from hollowing and cracks, and the veneer is vertical and flat, with square corners of Yin and Yang and straight joints. In order to ensure the quality of the project, it must conform to the relevant acceptance specifications. Once the on-site technicians find problems such as water seepage and falling, Party B shall be fully responsible for compensation, and Party B shall be responsible for compensation for reworked materials.
2. Construction safety: Before the project starts, it is necessary to carry out safety knowledge education, pay attention to their own safety and the safety of others, and educate construction personnel to abide by safety technical specifications. Ensure safe production and civilized construction, and put an end to safety accidents. In case of safety accident, Party B shall be responsible for its responsibilities and expenses, and Party A shall not bear any responsibilities and expenses.
Third, the construction progress
Party B must guarantee the construction progress of the project and carry out the construction in strict accordance with Party A's construction progress. If the delay is one day, the penalty will be 1 1,000 yuan, and so on. The timetable is detailed.
Fourth, the settlement method
Settle the spreading area of construction projects, and calculate scattered projects such as lines, beams and columns according to the actual spreading area. According to the actual expanded area of RMB/m2, excluding the area of doors and windows, including the scope of work such as mortar mixing, mortar transportation and cement mortar priming, Party B shall not do other decorative works such as convex window surfaces and bottom surfaces that do not stick porcelain surfaces.
Verb (abbreviation for verb) to pay
After the external wall starts, borrow meals in advance every 10 day. At the end of the month, 80% of the prepaid salary will be temporarily borrowed 10 yuan /m (including prepaid meals). After the external wall is pasted, it will be paid to 80% of the engineering quantity. 90% of the engineering quantity will be paid after the completion acceptance, and the remaining 65,438+00% will be paid five months later.
Other matters of intransitive verbs
1. During the construction of this project, Party B shall be responsible for all daily life and accommodation, and Party A shall not bear any expenses.
2. Matters not covered in this contract shall be settled by both parties through consultation.
3. This contract shall come into effect as of the date of signing, and neither party shall breach the contract. If one party breaches the contract, its economic losses shall be borne by the breaching party.
4. This contract is made in duplicate, one for each party.
Representative of Party A: Party B:
Date:
Shanghai Housing Decoration Simple Contract 6 Party A:
Party B:
According to the principles of the Economic Contract Law of the People's Republic of China and the Regulations on Construction and Installation Engineering Contracts, and in combination with the specific conditions of this project, the two parties have reached the following agreement:
Article 1 Project Date: Overview
1. 1 project name:
1.2 project site:
1.3 scope of construction:
1.4 construction contents:
1.5 construction period: it will be completed within 40 working days after the contract is signed and the mobilization time is approved by the supervision and project department.
1.6 project quality: it shall be implemented according to the acceptance standards of relevant industries in China.
The agreed price is 1.7: "Nippon" exterior wall coating 34 yuan /m2, interior wall putty powder Nippon coating 14.5 yuan /m2, toilet plastic gusset ceiling10 yuan /m2, and skirting line 4 yuan/m. Other expenses incurred according to Party A's requirements shall be settled according to the facts.
The total contract price is1.8: 500,000 yuan, which will be settled according to the actual engineering quantity after completion.
1.9 mode of payment: when Party B completes the exterior wall coating project, Party A will pay Party B 200,000 yuan, and when the interior wall of the project is completed, it will pay 654.38+million yuan, and the final payment will be paid in six months.
Article 2 Party A's responsibilities
2. 1 notify party b to enter the site three days in advance and make on-site technical disclosure to party b. ..
2.2 Provide Party B with construction convenience, remove obstacles that may affect the construction, provide Party B with self-provided water and electricity, and explain matters needing attention in use.
Article 3 Party B's responsibilities
3. 1 Strictly implement the construction specifications, safety operation procedures, fire safety regulations and environmental protection regulations. Carry out the construction in strict accordance with the drawings or work instructions, make records of various quality inspections, and accept the inspection and acceptance by Party A, the construction unit, the supervision company and the quality inspection station.
3.2 Abide by the regulations of the state or local government and relevant departments on the management of the construction site, properly protect the buildings, equipment and pipelines around the construction site from damage, and do a good job in the security and garbage removal of the construction site.
3.3 Before the completion of the project is handed over to Party A, Party A shall be responsible for the protection of all facilities and finished products on site.
Article 4 Time limit for a project agreement
4. 1 Party B must enter the site according to Party A's notice and synchronize with Party A's construction progress.
Article 5 Project Acceptance Agreement
5. 1 National construction and acceptance specifications such as construction drawings and specifications of this project are the acceptance criteria for quality evaluation.
5.2 The quality of this project should meet the national quality evaluation standards, and the single acceptance must be qualified at one time.
5.3 In case of quality accident or delay of construction period due to Party B, which causes economic losses to Party A, all expenses shall be borne by Party B, and the construction period shall not be postponed.
5.4 Party A shall, within one week after Party B completes the project quantity, check and accept the project quality and issue an acceptance certificate. Unqualified, as qualified.
Article 6 Project Payment and Settlement Agreement
6. 1 Settle according to the agreed unit price.
6.2 After the project is completed and accepted, Party B shall submit the project settlement and relevant materials to Party A for review.
6.3 Settlement of project funds: After the project is completed and accepted, both parties shall verify the completed engineering quantity submitted by Party B, and Party A shall pay all the final payment of the project to Party B at one time according to the actual engineering quantity agreed in the contract.
Article 7 Material Agreement
7. 1 All materials shall be purchased and constructed by Party B, and all materials must meet the requirements of the materials described in the design drawings. If the material does not meet the quality requirements or the specifications are different, it is forbidden to use it. If Party B fails to carry out the construction according to the above-mentioned material quality requirements or specifications, all losses caused to this project shall be borne by Party B. ..
Article 8 Agreement on Safety in Production and Fire Prevention
8. 1 During the construction period, Party B shall strictly abide by relevant laws and regulations such as Technical Specifications for Building and Installation Safety, Safety Operation Regulations for Building and Installation Engineering, and People's Republic of China (PRC) Fire Protection Regulations. And be responsible for the construction safety consequences caused by violation of the above provisions.
8.2 Party B shall bear all economic losses caused by safety or fire accidents due to violation of relevant safety operation regulations and fire regulations during construction and production.
Article 9 Reward and Liability for Breach of Contract
9. 1 If Party A's construction period is delayed and expenses are lost due to Party B's reasons, Party B shall bear all expenses.
9.2 Party B shall properly protect the finished products provided by Party A at the construction site, and compensate for any losses.
9.3 If Party A fails to go through the acceptance formalities and uses it in advance or without authorization, the losses caused shall be borne by Party A. ..
9.4 If the agreement cannot be continued due to one party's reasons, the other party shall be notified to terminate the agreement, and the responsible party shall compensate the other party for the economic losses caused thereby.
Article 10 dispute or dispute settlement
10. 1 During the performance of this agreement, if there is a dispute between the two parties, both parties can settle it through consultation or ask the relevant departments for mediation without affecting the progress of the project.
10.2 if both parties are unwilling to settle the dispute through negotiation or mediation, or negotiation or mediation fails, both parties agree that the dispute arising from the execution of this agreement shall be arbitrated by the local arbitration commission; If the parties have not agreed on an arbitration institution in this agreement and have not reached a situational arbitration agreement afterwards, they may bring a lawsuit to the people's court.
Article 11 Supplementary Provisions
This agreement is made in triplicate, with Party A holding two copies and Party B holding one copy.
1 1.2 This agreement will be automatically terminated upon completion of performance.
1 1.3 This contract shall come into effect after being signed and sealed by both parties.
Party A (seal): Party B (seal):
Authorized Agent: Authorized Agent:
Handler: Handler:
Bank of deposit: Bank of deposit:
Account number: Account number:
Date:
;