Renovation contract is an agreement between the decoration unit (the employer) and the decoration company (the contractor) on the house decoration of the employer. The following is a sample of the factory renovation contract I collected for you. Welcome to reading.
Model factory building renovation contract: entrusting party (Party A):
Organizer (Party B):
Engineering project:
Through friendly negotiation between Party A and Party B, Party A decided to entrust Party B to decorate Room 503, Dingjiaying Industry and Trade Building, Shajing, Hou Jing. In order to ensure the smooth progress of the project, this contract is specially signed for * * * to abide by.
I. Party A's responsibilities:
1. Party A shall hand over the design drawings to Party B, and with the consent of the property management department, cooperate with Party B in design and construction, such as elevator and goods storage.
2. In the process of construction, if it is necessary to modify, Party B shall be informed in time.
Two. Party B's responsibilities:
1. Party B is responsible for purchasing and installing flame-retardant cotton steel plates (the thickness is subject to model 4 16), geosynclines, edge sealing, door opening, locking, disassembly and other equipment, and providing corresponding material invoices and material inspection certificates.
2. If the unqualified materials affect the project quality and time limit for a project, Party B shall bear the expenses of materials and rework.
3. This project belongs to the all-inclusive project form of Party B's enterprise, and Party B promises to purchase relevant insurance for Party B's construction personnel to ensure the safety of Party B's construction personnel. In case of safety accident, Party B shall be responsible for it, which has nothing to do with Party A. ..
4. Party B is responsible for providing Party B's business license, membership card or construction qualification to Party A for filing.
5. Party B appoints (name) _ _ _ _ _ _ _ _ as the project leader of Party B, who is responsible for signing the contract, guiding the site construction as required, ensuring site safety and preventing unsafe factors such as fire and electricity consumption. All construction personnel must hold relevant certificates and conduct civilized construction, so as to prevent accidents such as pipeline blockage, water leakage, power jump and damage caused by construction from affecting others.
Three. Other agreements:
1, project quality acceptance, except for concealed works, which need to be accepted by sections, Party B shall organize Party A to conduct completion acceptance after all projects are completed. Both parties shall handle the project settlement and handover procedures.
2. Strictly perform the contract and implement the credit period. If the completion is delayed due to out-of-production, slowdown or excuses to induce Party A to pay in advance, it shall be regarded as a breach of contract after investigation.
3. The renovation period is __ 12__ days from the effective date of this contract.
4. Party B shall undertake the warranty responsibility within the scope of installation and construction. The warranty period is 12 months, counting from the date when the project is completed and accepted by Party A. ..
Four. Project cost agreement: (All-inclusive price of finished products of each project)
1, single door: 280 yuan/fan
2. Gate 2: 560 yuan/Fan.
3. Partition wall: 102 yuan /m2 (including opening doors and windows), measured after completion.
4. Window opening: 1.65m * 0.9m, 350 yuan/fan.
5. Heightening project: 1000 yuan.
6. Mobile air shower room project: 1 ten thousand yuan.
7. Hydropower project (all projects): 4,500 yuan.
Verb (abbreviation of verb) liability for breach of contract
After the contract comes into effect, during the performance of the contract, the party that terminates the contract without authorization shall pay _50_% of the total contract amount to the other party as liquidated damages. If it is actually caused by the other party's violation of the terms of this agreement, it shall be compensated.
Dispute resolution of intransitive verbs;
In case of any dispute during the performance of this contract, both parties shall settle it through consultation without affecting the project progress. If negotiation fails, a lawsuit can be brought to the people's court according to this contract.
Seven. Entry into force of contract
1. This contract and the drawings attached to it shall be sealed by both parties and come into force after being signed.
2. The supplementary contract has the same legal effect as this contract.
3. This contract (including annexes and supplementary contracts) is made in duplicate, with each party holding one copy.
Party A: (signature and seal)
Signature of Party A's representative:
Party B: (signature and seal)
Signature of Party B's representative
Year month day:
According to the Contract Law of People's Republic of China (PRC) and relevant laws and regulations, combined with the characteristics of family room decoration project, both parties reached the following agreement on matters related to the family room decoration project of the Employer (hereinafter referred to as the project) on the basis of consensus:
Article 1 General situation of the project
1. 1 Project location:
1.2 project contents and practices (see annex list).
1.3 project contracting method: both parties agree to adopt the following _ _ _ contracting method.
(1) Contractor's contracted works and materials;
(2) The contractor contracts, part of the package materials (list of decoration materials provided by the contractor) and part of the materials provided by the employer (list of decoration materials provided by the employer);
(3) Contractor contracting and employer contracting (the employer provides a list of decoration materials).
1.4 The construction period is 30 days, and the commencement date is 2065438+_ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _.
1.5 contract price: the project cost of this contract is (in words): _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _
Article 2 Where a project supervisor supervises a project, the employer and the supervision unit shall separately sign a project supervision contract, and notify the contractor of the name, unit, contact information and responsibilities of the supervision engineer.
Article 3 Construction Drawings Both parties agree that the construction drawings shall be provided in the following ways:
(1) The employer shall design and provide the construction drawings in duplicate, one for the employer and one for the contractor (see the design drawings of family room decoration engineering for details);
(2) The employer entrusts the contractor with the design and construction drawings in duplicate, one for the employer and one for the contractor (see the design drawings of family room decoration engineering for details), and the design fee is (in words) _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _, which shall be paid by the employer (this fee is not included in the project price).
Article 4 Obligations of employers
4. 1 Create conditions for the contractor to enter the site before construction. Including: on the principle of not affecting construction, demolishing or stacking indoor furniture and furnishings, and covering indoor furniture and furnishings that are not easy to move;
4.2 Provide water and electricity supply during construction;
4.3 Participate in the supervision of project quality and construction progress, and be responsible for the material mobilization and completion acceptance.
Article 5 Obligations of the Contractor
5. 1 During construction, strictly implement the safety construction operation specifications, fire prevention regulations, construction specifications and quality standards, and complete the project with good quality on schedule;
5.2 Strictly implement the construction site management regulations, and do not disturb the people or pollute the environment;
5.3 Protect the furniture and furnishings of the original living room and ensure the smooth flow of the upper and lower water pipes in the living room;
5.4 Ensure the cleanliness of the construction site, and be responsible for the cleaning of the construction site after the project is completed.
Article 6: Terms and Methods of Payment
6. 1 payment terms: payment after renovation and inspection;
6.2 Payment method: check or telegraphic transfer
Article 7: Project Acceptance
7. 1. Project quality acceptance: After all projects are completed, Party B shall organize Party A to carry out the completion acceptance. Both parties shall handle the project settlement and handover procedures.
7.2. After Party B notifies Party A to carry out process acceptance and completion acceptance, Party A shall come for acceptance within three days.
Article 8: Other matters
8. 1. Party A
(1) The house plan and water, electricity and gas circuit diagram approved by the property management department must be provided, or Party A shall provide the house plan and water, electricity and gas circuit diagram, and make on-site disclosure to Party B. ..
(2) Secondary decoration project, in which all or part of the house is vacated and obstacles affecting the construction are removed. Necessary protective measures shall be taken for furniture and furnishings that can only be partially vacated in the house, and all formalities shall be handled with Party B, and the expenses shall be borne by Party B..
(3) If it is really necessary to dismantle or change the original building structure or equipment and pipelines, it shall go through the formalities with the local housing management department and bear the relevant expenses. If you need to use public parts temporarily during construction, you should say hello in advance.
8.2 Party B
(1) should take the initiative to show business license, membership card or construction qualification; If it is a subordinate branch, it must also have a certificate issued by the superior company; The handling salesman must have a certificate of entrustment from the legal representative.
(2) Be responsible for the safety, fire prevention, related certificates and civilized construction of the construction site, so as to prevent accidents such as pipeline blockage, water leakage, power failure and damage to articles caused by construction from affecting others. If it happens, it must be repaired or compensated as soon as possible.
(3) Strictly perform the contract and implement the credit period. If the completion is delayed due to out-of-production, slowdown or excuses to induce Party A to pay in advance, it shall be regarded as a breach of contract after investigation.
(4) undertake the warranty responsibility within the scope of decoration construction, and the warranty period is 12 months from the date when the project is completed and accepted by Party A. ..
Article 9: Liability for breach of contract
After the contract comes into effect, during the performance of the contract, the party that terminates the contract without authorization shall pay% of the total contract amount to the other party as liquidated damages. If the actual loss caused to the other party by the unauthorized termination of the contract exceeds the liquidated damages, it shall be compensated.
Article 10: dispute settlement
10. 1. In case of any dispute during the performance of this contract, both parties shall settle it through negotiation without affecting the project progress. Or bring this contract and the unified invoice issued by Party B to complain to the Home Decoration Professional Committee of the Interior Decoration Industry Association of the city and demand settlement.
10.2. If both parties are unwilling to settle the dispute through negotiation or mediation, or negotiation or mediation fails, they may apply to the Arbitration Commission for arbitration according to this contract; -the people's court brought a lawsuit.
Article 11: Modification and Termination of the Contract
1 1. 1. After this contract comes into effect after being signed by both parties, both parties must strictly abide by it. If either party needs to change the contents of the contract, it shall sign a supplementary agreement after both parties reach an agreement through consultation. If it is necessary to terminate the contract, the party who proposes to terminate the contract shall do so in writing, pay liquidated damages at% of the total contract price, and go through the termination procedures.
1 1.2. During the construction process, any party who proposes to terminate the contract shall submit it to the other party in writing, and the contract shall be deemed to be terminated after the liquidation procedure is agreed by both parties. Article 12: Contract comes into effect
12. 1. This contract and its annexes shall be sealed by both parties and come into force after being signed.
12.2. The supplementary contract has the same legal effect as this contract.
12.3. This contract (including annexes and supplementary contracts) is made in duplicate, with each party holding one copy. Party A (owner): _ _ _ _ _ _ _ _ _ _ (signature) Party B: _ _ _ _ _ _ (signature) Address: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _
Postal Code: _ _ _ _ _ _ _ _ _ _ _ _ _ Postal Code: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _
;