Current location - Plastic Surgery and Aesthetics Network - Wedding planning company - The latest model of 2022 hotel renovation contract
The latest model of 2022 hotel renovation contract
Employer of model contract: _ _ _ _ _ _ _ _ _ _ _ _ Contractor: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ Designer of this project: _ _ _ _ _ _ Tel: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ Based on the characteristics of the family room decoration project, the two parties reached the following agreement on matters related to the family room decoration project of the Employer (hereinafter referred to as the project) on the basis of equality, voluntariness and consensus: Article 1: Project Overview 1. 1 Project Location: _ _ _ _ _ _ _ _ _ _ _ _ _ _. Schedule 2: List of Contents and Practices of Family Room Decoration Project). 1.3 project contracting mode: both parties agree to adopt the following _ _ _ contracting mode. (1) Works and materials contracted by the contractor (see Schedule 5: List of Decorative Materials Provided by the Contractor for details); (2) The contractor contracts some materials and the employer provides some materials (see Schedule 4: List of Decorative Materials Provided by the Employer for details). Schedule 5: List of Decorative Materials Provided by the Contractor); (3) The contractor contracts the project and the employer contracts the materials (see Schedule 4: List of Decorative Materials Provided by the Employer for details). 1.4 The construction period of the project is _ _ _ _ _ _ _ _ _ _ _ 1.5 Contract price: the construction cost of this contract is (in words): _ _ _ _ _ _ _ _ _ _ (see Annex III for details: quotation for family room decoration. Article 2 Where a project is supervised by a project supervisor, the employer and the supervision unit shall separately sign a project supervision contract and notify the contractor of the name, unit, contact information and responsibilities of the supervision engineer. Article 3 Construction Drawings Both parties agree to provide the construction drawings in the following ways: (1) The employer shall design and provide the construction drawings in duplicate, one for the employer and one for the contractor (see Annex 6: Design Drawings of Family Room Decoration Project for details); (2) The Employer entrusts the Contractor to design and construct the drawings in duplicate, one for the Employer and one for the Contractor (see Schedule 6: Design Drawings of Family Room Decoration Project for details), and the design fee is (in words) yuan, which shall be paid by the Employer (this fee is not included in the project price). Article 4 The Employer has the obligation to create conditions for the contractor to enter the site for construction 4. 1 day before commencement. Including: demolition of indoor furniture and furnishings, or stacking and covering indoor furniture and furnishings that are not easy to move on the principle of not affecting construction; 4.2 Provide water and electricity supply during construction; 4.3 Responsible for coordinating the relationship between the construction team and the neighborhood; 4.4 The indoor load-bearing structure shall not be dismantled. If it is really necessary to dismantle the non-load-bearing structure or equipment pipeline of the original building, go through the corresponding examination and approval procedures with the relevant departments; 4.5 During the construction period, if the Employer still needs to use the bedroom partially, it shall be responsible for the public security and fire control of the construction site. 4.6 Participate in the supervision of project quality and construction progress, and be responsible for the material mobilization and completion acceptance. Article 5 The contractor must strictly implement the safety construction operation specifications, fire prevention regulations, construction specifications and quality standards during construction, and complete the project with good quality on schedule. 5.2 Strictly implement the construction site management regulations, and do not disturb the people or pollute the environment; 5.3 Protect the furniture and furnishings of the original bedroom, and ensure that the water pipes in the bedroom are unblocked; 5.4 Ensure the cleanliness of the construction site, and be responsible for the cleaning of the construction site after the project is completed. Article 6 If the project and construction method need to be changed in the project change, both parties shall reach a consensus through consultation, sign a written change agreement, and adjust the related project cost and construction period (see Schedule 7: Family Room Decoration Project Change Order). Article 7 Provision of Materials 7. 1 For the materials and equipment provided by the Employer (see Schedule 4: List of Decorative Materials Provided by the Employer), the Employer shall notify the Contractor before the materials arrive at the construction site, and both parties shall accept them and handle the handover procedures; 7.2 For the materials and equipment provided by the Contractor (see Schedule 5: List of Decorative Materials Provided by the Contractor), the Contractor shall notify the Employer before the materials are transported to the construction site and accept the inspection by the Employer. Article 8 Delay of construction period 8. 1 If the completion date is delayed due to the following reasons, the construction period will be postponed accordingly upon confirmation by the Employer: (1) Engineering quantity change and design change; (2) Force majeure; (3) Other circumstances in which the Employer agrees to postpone the construction period. 8.2 If the time limit for a project is affected by the failure of the Employer to complete the work it should be responsible for as agreed, the time limit for a project will be postponed; If the quality of the project is affected by the unqualified materials and equipment provided by the employer, the cost of rework shall be borne by the employer, and the construction period shall be postponed. 8.3 If the Employer fails to pay the project payment on schedule, the contract period shall be postponed accordingly. 8.4 If the construction period is affected due to the contractor's failure to start construction on schedule or stop work halfway for no reason, the construction period will not be postponed; If there is any problem with the project quality due to the contractor, the cost of rework shall be borne by the contractor, and the construction period shall not be postponed. Article 9 Quality Standards Both parties agree that the construction quality standard of this project is _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ Article 10 Project Acceptance and Warranty 10. 1 Both parties agree to accept the project quality in the following stages during the construction process: (1) _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _; (2)_________________________; (3) After the completion of the project, the contractor shall notify the Employer for acceptance, and the Employer shall organize acceptance within two days after receiving the acceptance notice, and fill in the project acceptance sheet (see Schedule 8: Acceptance Sheet for Family Room Decoration Project). After the project payment is settled, handle the handover procedures (see Schedule 9: Statement of Family Room Decoration Project for details). 10.3 The warranty period of this project is _ _ months from the date of acceptance and signature by both parties. After the acceptance and signature, fill in the project warranty form (see attached table 10: warranty form for family room decoration project). Article 11 Payment method of project funds: 1 1. 1 Both parties agree to pay the project payment in the following ways: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ Human-paid project funds: more than half of the project progress refers to _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ Both parties shall fill in the project settlement form (see Schedule 9: Settlement Form of Family Room Decoration Project) and sign it. The Employer shall settle the final payment of the project with the Contractor when signing the contract. | Payment Times | Payment Time | Payment Amount ||| First payment | Three days before commencement | Second payment | More than half of the project progress | Payment || Third acceptance by both parties | Payment |1.3 After all the project funds are settled, the contractor shall issue a formal unified invoice to the employer. Article 12 Liability for breach of contract 12. 1 Any party that fails to perform the contract or violates national laws, regulations and relevant policies shall bear the responsibility and compensate the other party for its economic losses. 12.2 The Employer shall be responsible for the losses caused by the Employer's use of the completed project in advance or without going through the acceptance formalities. 12.3 if the contract cannot be continued due to one party's reasons, that party shall promptly notify the other party and go through the contract termination procedures, and the responsible party shall compensate the other party for the corresponding economic losses. 12.4 If the Employer fails to pay the second (third) project payment on schedule, it shall pay the other party RMB as penalty for each day of delay. 12.5 if the quality of the project fails to meet the quality standards agreed by both parties due to the contractor, the contractor shall be responsible for the repair, and the construction period will not be postponed. 12.6 If the construction period is delayed due to the contractor's reasons, the contractor shall pay the other party RMB as liquidated damages for each day of delay. Article 13 Settlement of Contract Disputes Disputes arising from the performance of this contract shall be settled by both parties through consultation; Can also be mediated by the relevant departments; If negotiation or mediation fails, it shall be settled in the following _ _ _ _ way: (1) submit it to _ _ _ _ Arbitration Commission for arbitration; (two) to bring a lawsuit to the people's court according to law. Article 14 stipulates that the garbage generated by the project construction shall be transported out of the construction site by the contractor and transported to the designated place, and the employer shall be responsible for paying the garbage removal fee (in words) _ _ _ _ _ _ _ (this fee is not included in the project price). 14.2 during the construction period, the employer will give the key of the outhouse to the contractor for safekeeping. After the project is completed and accepted, the employer is responsible for providing new locks, and the contractor is responsible for site installation and delivery. 14.3 During the construction period, the contractor's daily working hours are: from _ _ _ to _ _ _ and from _ _ _ to _ _ _ in the afternoon. Article 15 Other agreed matters: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _. 16.2 after the signing of this contract, the project shall not be subcontracted. 16.3 this contract is in duplicate, and each party holds _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _. 16.4 annexes to this contract are an integral part of this contract and have the same legal effect as this contract. Employer (signature): _ _ _ _ _ _ _ _ _ _ _ Contractor (seal): _ _ _ _ _ _ _ _ _ _ _ _ _ Legal representative: _ _ _ _ _ _ _ _ _ _. Agent: signing date: _ _ _ _ _ _ _ _ _ _ _ In reality, the decoration of the hotel is actually different from that of your own home. After all, the hotel is a business place, and the parties want to decorate it at the lowest cost, but the house is where they live with their families, so the use of materials may be better.