Phase construction contract 1 phase construction contract
Party A: (hereinafter referred to as Party A)
Party B: (hereinafter referred to as Party B)
In accordance with the Contract Law of People's Republic of China (PRC) and relevant laws and regulations, and following the principles of equality, voluntariness, fairness and good faith, both parties have entered into this contract on matters related to stage construction and construction project through consultation.
1. Party A entrusts Party B to design and manufacture the stage structure (see the drawings for details):
1. 1, stage address:
1.2. Stage area: length: meter, width: meter, area: square meter;
1.3. Contract price: RMB (in words) only.
1.4. Project content: stage welding, wooden floor laying and first floor carpet decoration.
1.5. The price includes design fee, production fee, material fee, construction management fee, electricity fee and water fee.
Party A does not need to pay any other expenses to Party B for the expenses, transportation expenses, loading and unloading expenses, labor expenses, insurance premiums, taxes and other expenses required by Party B to complete the work agreed in this contract. ..
2. The project cost payment, way:
2. 1. After the contract comes into effect, Party A shall pay Party B 80% of the project price, namely RMB (in words).
2.2 After the stage acceptance,
20% of the project cost, namely RMB (in words) (Yuan)
Currency yuan)
2.3. Payment method: cash and bank remittance.
Three. contract period
3. 1, commencement date _ _ _ _ _ _ _ _
3.2. Completion Date _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _
4. Quality requirements and responsibilities:
4. 1 day to complete all the fabrication and installation of this stage.
4.2 Party B must decorate and decorate in strict accordance with Party A's quality requirements.
Verb (abbreviation of verb) acceptance:
5. 1 year
5.2. Acceptance criteria: The renderings confirmed by both parties shall prevail.
5.3. Party A shall conduct the acceptance according to the quality requirements specified in the contract and the renderings.
5.4. The parts that need to be rectified during acceptance shall be rectified through negotiation after Party A and Party B define their responsibilities until the requirements agreed by both parties are met; All expenses incurred shall be borne by the responsible party.
Liability for breach of contract of intransitive verbs:
(1) Party A's responsibilities:
1. 1. Party A must pay the project payment on time, otherwise Party B has the right to stop the project at any time, and all the consequences arising therefrom shall be borne by Party A without any responsibility.
1.2. If Party A breaches the contract in the production process, Party B will not refund the advance payment.
1.3. Party A promises to sign a fire protection agreement.
1.4. Party A shall bear the electricity fee at this stage.
(II) Party B's responsibilities:
2. 1. Party B must manufacture and install according to the design drawings, and shall not change the design without authorization.
2.2. Party B must complete the phased construction within the specified time, or bear the corresponding responsibilities.
2.3. The stage built by Party B must be safe and reliable, but it is not caused by Party B's reasons or force majeure. Party B is not responsible for compensation for losses; Before Party A pays off the balance of the project, the ownership of all the goods still belongs to Party B. ..
2.4. The buildings and materials used by Party B must comply with the fire safety regulations.
2.5. During the construction period, Party B shall strictly abide by Technical Regulations for Safety of Construction and Installation Engineering, Safety Operation Regulations for Construction and Installation Workers, People's Republic of China (PRC) Fire Protection Regulations and other relevant laws and regulations.
2.6. Party B is responsible for the safety of the construction site and its construction personnel. If Party B violates the relevant safety operation rules and fire regulations in the construction and production process, resulting in safety or fire accidents and other liability accidents, Party B shall bear all the economic losses arising therefrom.
Seven. This contract shall come into effect as of the date of signature and seal by both parties, and matters not covered in this contract shall be settled by both parties through consultation; If a supplementary agreement is reached, the supplementary agreement has the same legal effect as this contract. If negotiation fails, it shall be under the jurisdiction of the court of Party A's domicile. This contract is made in duplicate, the fax is valid, and each party holds one copy, which has the same legal effect.
Signature of Party A: Signature of Party B:
Seal: seal:
Date: Year Month Day Date: Year Month Day
Phased construction contract
ContractNo.: LYD20 1004 15
Party A:
Address:
Party B:
Address:
Party A will hold the "20xx Top Ten Awards Gala of China's Hardware Industry-Launching Ceremony of 20xx China Hardware Brand Fashion Festival" at Diaoyutai State Guesthouse on xx, xx, and now entrusts Party B to complete the stage and AV construction and other related contracting work. After consultation, both parties signed the following contract.
I. Construction contents:
1. Party B is responsible for the construction and management of contracted projects such as event stage, audio-visual equipment, etc. (see Annex I for the quotation of specific contracted projects);
2. For Party B's contract works and materials, Party B must select raw materials according to the contract provisions and accept Party A's inspection ... If Party B conceals the defects of raw materials or uses raw materials that do not meet the contract requirements, which affects the quality of crops, Party A has the right to request rework and repair.
Second, the quality requirements and technical standards:
Meet the design renderings standards approved by Party A. ..
Three. Time limit for Party B to complete the work and the conditions and time limit for being responsible for the quality:
Party B shall enter the activity site before 6:5438+07:00 pm on xx, xx, xx, and complete the layout, installation and debugging of the above-mentioned venue before 22: 00 pm on XX, XX, XX, and pass the acceptance of Party A. During the official activities and performances, Party B's on-site equipment operators shall handle the above-mentioned stage effects according to Party A's requirements to ensure the smooth progress of meetings and activities.
Four, technical data, drawings to provide methods:
1. Where Party A provides the design scheme, Party A shall submit the confirmed design scheme to Party B months in advance;
2. Party B shall complete the project as scheduled according to the technical specifications and quality required by Party A. If Party A finds that there are quality problems in Party B's work, Party B shall take effective measures to correct them within the notification day of Party A..
Verb (abbreviation of verb) acceptance criteria and time limit:
1. acceptance criteria: as stipulated in the contract and its annexes;
2. Acceptance time: at 22: 00 of the current month, the event will be accepted on site.
VI. Installation and Withdrawal
1. Party A's activity venue is used to transport materials to the above-mentioned place designated by Party A. ..
2. Party B shall, on.
7. Settlement method, term and deposit of advance payment.
1, and the total contract price is RMB (including tax). See Annex I for all specific quotation items.
2. Party A shall pay the advance payment to Party B within working days after the signing of the contract. After the project passes the acceptance of Party A, Party A shall pay the balance of 8,000 yuan to Party B on the day of the activity.
three
However, if the deduction items are generated in the later stage of the activity, Party A shall be responsible for the deduction expenses in cash.
Eight. responsibility for breach of contract
1, Party A's liability for breach of contract
(1) For reasons that cannot be agreed, Party A unilaterally terminates the contract in advance before Party B enters the site for construction, and pays the liquidated damages of the total contract price to Party B; If Party B has started to arrange for Party A to unilaterally terminate the contract in advance, Party A shall pay Party B a penalty of 65,438+000% of the total contract price.
(2) If Party A delays payment, Party A shall pay 0% of the overdue payment amount to Party B as liquidated damages for each overdue day;
(3) If Party A fails to pay the advance payment to Party B on time, Party B has the right to unilaterally terminate the cooperation under this contract. Party B has not breached the contract.
2. Party B's liability for breach of contract:
If Party B changes or terminates the contract without Party A's consent, or Party B fails to complete the contracted project on time and with good quality as stipulated in this contract, Party A has the right to deduct the contract amount of the corresponding project and require Party B to pay a penalty equivalent to 50% of the contract amount.
9. Party B shall bear all risks before delivering the crops or work stipulated in the contract and passing the acceptance of Party A. ..
X. Ways to resolve contract disputes: through consultation; If negotiation fails, it shall be under the jurisdiction of the court where Party A or Party B is located.
XI。 Other terms agreed by both parties.
1. This contract is concluded in accordance with the Contract Law of People's Republic of China (PRC);
2. The payment period of liquidated damages and compensation shall be within 10 days from the date of the observant party's notice;
3. Party B shall be responsible for safety measures and management of contractors according to its responsibilities, and abide by and implement the provisions on safe and civilized contracting;
Twelve. supplementary terms
1. For matters not covered in this contract, both parties shall negotiate and sign a supplementary contract. If the supplementary contract is inconsistent with this contract, the supplementary contract shall prevail.
2. This contract shall come into effect as of the date of signature and/or seal by both parties.
3. The annexes to this contract are an effective part of this contract:
Attachment 1: Party B's quotation;
4. This contract and its annexes are made in duplicate, one for each party, with the same legal effect.
All artificially modified parts of the contract are invalid.
Party A: Party B:
Representative: representative:
Date of signature: xx, xx, xx, XX.
Stage Construction Contract Article 3 Stage Construction Contract of Activity Site
According to the Contract Law of People's Republic of China (PRC), the Law of People's Republic of China (PRC) on the Protection of Consumers' Rights and Interests and relevant laws and regulations, combined with the specific conditions of this celebration service, Party A and Party B reached an agreement through consultation on the basis of following the principles of voluntariness, equality, fairness, honesty and credit.
Party A:
On behalf of:
Party B: Hefei Renquantang Media Co., Ltd.
On behalf of:
Through friendly negotiation, Party A and Party B have reached an agreement that Party A will hold the anniversary celebration on xx, xx. Both parties agree as follows:
1. Activity time: xx, xx, XX.
2. Venue:
3. Activity theme:
4. The total contract amount signed by Party A and Party B: 13295.00 Yuan only.
Amount in words: thirteen thousand two hundred and ninety-five yuan only.
5. Payment method:
Within three working days after signing the contract, Party A shall pay the contract price in one lump sum.
6. Liability for breach of contract:
Both parties shall abide by the contract, and neither party shall breach the contract at will. In case of breach of contract, 20% of the total contract amount shall be paid to the other party as liquidated damages. If it is really necessary to change the contract, it can only be changed after both parties agree through consultation, otherwise, the other party shall be compensated for the losses caused thereby and bear legal responsibilities.
7. Matters not covered and additional clauses
1) Matters not covered in this contract shall be determined by both parties through consultation and a written agreement shall be signed as an annex to this contract;
2) Additional clauses of this contract are as follows:
P4LED color display 2.5X6m: 3900 yuan
8 sets of beam lights: 2240 yuan
Handkerchief lamp contains 8 lamps: 480 yuan.
/kloc-2 sets of 0/200w spotlights: 400 yuan
Stage building 7.5m x 5m x 0.3m: 1600 yuan.
The new red carpet on the stage is 48 square meters: 384 yuan.
Camera SLR dual camera 1800 yuan
Bee Microphone 4: 480 yuan
Photo board 1.8m× 2m, diameter 1m turntable, photo OEM, activity theme design, etc. : 500 yuan.
4. Car freight: 1000 yuan
* * * Yuan: 12784.
Tax: 5 1 1 yuan.
Total: 13295 yuan
8. This contract shall come into effect as of the date of signature (seal) by both parties. This contract is made in duplicate, both of which are equally authentic. Party A and Party B each hold one copy.
Party A (signature): Party B (signature):
Xx，xx，XX，XX