Construction project contract 1
Employer: (hereinafter referred to as Party A)
Contractor: (hereinafter referred to as Party B)
In accordance with the Contract Law of People's Republic of China (PRC) and other relevant laws and regulations, and following the principles of equality, voluntariness, fairness, honesty and credibility, both parties reached an agreement on project contracting and signed this contract.
Article 1: Project Overview
The contracted project of lakeside slope protection project is contracted to Party B, and the construction is contracted with materials. The total length of lakeside slope protection is calculated in meters.
Article 2: Construction Scheme
1, slope protection
(1), the base is meters wide, meters thick and meters high from bottom to top. Cold-drawn brick belt is needed for the stressed part, and sand grinding is needed for the external wall (cement grade 42.5, brick should be blue brick or red brick with good quality).
(2) Demolition of three houses next to the toilet for access.
(3) The completed fence is about10m.
(4) The gap between the wall and the bank should be tamped with soil, and an appropriate amount of leaking pipes should be added to the wall.
Article 3: Term of Contract
1. The construction period is days as determined by both parties through negotiation, tentatively starting from year month day to year month day. The specific commencement time can only be started after Party A issues the commencement order.
2. In case of force majeure during construction, or Party A requests Party B to stop work, the construction period will be postponed accordingly.
Article 4: Price and Payment Method
1, and the total contract price of the project is RMB.
2. The above-mentioned total contract price is lump sum price, including all work contents, labor and materials contracting and all other expenses (including house demolition and fence) of this contract, and Party A does not need to pay any more expenses to Party B. ..
3. Payment method: RMB yuan will be paid after the completion acceptance, and the rest will be paid after one year (counting from the date of acceptance) except 5% of the total amount.
Article 5: Obligations of Party A
1. Allocate project funds to Party B according to the contract.
2. Assist in coordinating matters such as temporary water and electricity use on the construction site.
Article 6: Obligations of Party B
1. The contractor is responsible for supervising and inspecting the quality, progress and safety of the project, handling daily related matters and ensuring the safety and stability of the project construction.
2. The contractor must complete the contracted project and shall not subcontract it to others.
Article 7: Construction Safety
The contractor shall abide by the relevant provisions of the project construction safety production management, organize the construction in strict accordance with the safety standards, and take necessary safety protection measures to eliminate the hidden dangers of accidents. Party B shall bear all responsibilities and expenses caused by accidents in the construction process.
Article 8: Acceptance
The project completion acceptance shall be based on the construction scheme and quality acceptance standard. If the acceptance is unqualified, Party B shall be responsible for rework for free.
Article 9: Liability for breach of contract
1. Party A shall pay the project payment in time as agreed in this contract. In case of overdue, Party A shall pay liquidated damages to Party B (the interest shall be calculated according to the bank loan interest rate of the payable amount for the same period).
2. If Party B fails to complete the project on schedule due to reasons other than Party A's or force majeure, Party B shall pay liquidated damages of 1% of the total project amount to Party A for each day overdue; If the overdue period exceeds ten days, Party A has the right to unilaterally terminate the contract.
Article 10: Other
This contract is signed by both parties on, and takes effect after being signed or sealed by both parties. It is made in duplicate, one for execution and one for delivery.
Employer (Party A) (Seal)
Authorized agent (signature or seal):
Contact telephone number:
Contractor (signature or seal):
Contact telephone number:
date month year
Employer (Party A): _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _
Address: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _
Legal Representative: _ _ _ _ _ _ _ Title: _ _ _ _ _ _ _
Contractor (Party B): _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _
Address: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _
Legal Representative: _ _ _ _ _ _ _ Title: _ _ _ _ _ _ _
Construction project contract 2
Party A (contractor):
Party B (contractor):
Because Party A needs to carry out foundation decoration for the office building of the newly-built heating station, it is decided that Party B will be responsible for the completion of the project through negotiation between Party A and Party B. In order to clarify the responsibilities of both parties and ensure the safety, quality and progress of the construction, the following clauses are hereby made for both parties to abide by.
First, the project content:
Some areas are newly decorated.
Second, the project settlement price and payment method:
According to the budget quota of repair and installation project in Taiyuan City in 20__ and unified installation project in Shanxi Province in 20__ _, no other expenses are taken, only 8% of taxes and management fees are taken, and the site visa is paid in one lump sum after the project is completed and accepted.
Third, the construction period:
From 20__ year 10 month/day to 20__ year 1 0 month/day. If Party B fails to complete the project on schedule, the project cost will be deducted by RMB 65,438+0,000 for each day overdue.
Fourth, the way of contracting:
Party B shall undertake the work and materials.
Five, the project quality:
1. Party B must carry out the construction according to the current national engineering quality and technical standards and specifications.
2. If the project quality is unqualified due to Party B, Party B shall rework it free of charge within the time specified by Party A in order to reach the acceptance standard of the project quality. If the rework still fails to meet the requirements, Party B shall be liable for breach of contract.
Six, project acceptance:
After the completion of all projects, Party A will organize acceptance, and unqualified projects will not be accepted.
Seven, construction safety:
Party B is the first person responsible for safety construction, and it must be civilized and safe in the construction process. All safety accidents in the construction process shall be borne by Party B. ..
Eight. Matters not covered in this contract shall be settled through consultation in accordance with relevant regulations.
This contract is made in quadruplicate, with the same legal effect.
Representative of Party A: Representative of Party B:
Date of signature: year month day.
Construction project contract 3
Employer: _ _ _ _ _ _ _ (hereinafter referred to as Party A)
Construction Team: _ _ _ _ _ _ _ _ _ (hereinafter referred to as Party B)
According to the Contract Law of People's Republic of China (PRC), the Construction Law of People's Republic of China (PRC) and other relevant laws and regulations, following the principles of equality, voluntariness, fairness, honesty and credit, and in order to ensure the construction period, quality and safety of the project, and clarify the responsibilities, rights and interests of both parties, Party A agrees to contract the reinforcement project of the newly-built Zhanyi station building after the second line station of Shanghai-Kunming Railway is added to Party B..
I. Overview of the Project:
Project name: Liu Zhan Second Line Station of Shanghai-Kunming Railway is newly added, and Zhanyi Station Building is newly built.
Second, the scope of contracting:
According to the design drawings of this project (including change notice), all reinforcement works required.
Third, the acceptance method:
According to this contract, the current national construction and acceptance specifications for construction and installation projects, the quality evaluation standards for construction and installation projects and the regulations of relevant departments, the acceptance shall be carried out in strict accordance with the requirements.
Four. Unit price and payment method:
1, _ _ _ _ _ _/ton.
2. Pay the progress payment according to the quantities. After the completion of the project, the final payment shall be paid in one lump sum after passing the acceptance.
Verb (abbreviation of verb) Obligations of Party A:
1, provide drawings on time, supply required steel bars, and provide steel bar production sites.
2. Be responsible for contacting Party B, supervision, design and relevant departments, and coordinating the working relationship on site.
3. Make technical disclosure to Party B before construction to provide reasonable and favorable construction conditions for Party B. ..
4. Party A shall provide wire binding.
The intransitive verb obligations of Party B:
1. Organize skilled workers with corresponding qualification certificates to take up their posts.
2. Carefully organize the construction in strict accordance with the design drawings, construction acceptance specifications, relevant technical requirements and construction organization design to ensure that the project quality meets the agreed standards; Scientifically arrange the operation plan; Guarantee the construction period; Strengthen safety education, conscientiously implement safety technical specifications, strictly abide by the safety system, and implement safety measures to ensure construction safety; Bear the losses caused by quality modification, rework, construction delay, safety accidents, messy site and various fines due to their own responsibilities.
3. Strictly implement the current construction and acceptance specifications of graphic designers, and ensure that the construction tasks are completed on schedule with good quality and quantity.
4. Obey the management and command of Party A's on-site construction personnel, save materials, and it is forbidden to be overqualified, superior and inferior, and waste materials.
5. The specifications, dimensions and positions of steel bar fabrication and binding shall be accurate and meet the requirements of design and construction specifications. Quality objectives require excellent results. If the quality is not up to standard, Party B shall immediately rework it until it is up to standard, and all labor, materials and other expenses arising from rework shall be borne by Party B. ..
6. When pouring concrete, Party B must send enough people to watch the reinforcement. It is forbidden to throw steel bars and other materials at high altitude, and the materials should be classified and stacked neatly according to the location designated by the site management personnel. All production sites should be clean and tidy.
7, steel blanking, blanking sheet must be approved by Party A's engineer or the builder's technician before blanking.
8. Ensure the construction quality of the undertaken project, the time limit for a project and the construction progress formulated by Party A, obey the management of Party A's on-site construction management personnel, and abide by the national, local and construction site systems.
Seven. Safety requirements
1. Party B must pay attention to safety production and civilized construction, strictly abide by the relevant national safety operation regulations and the relevant safety and civilized construction regulations of the company and the site, and strictly prohibit illegal operations. Party B shall bear the economic and criminal responsibilities for all major and minor casualties caused in the construction process, and Party A shall not bear any responsibilities.
2. Party B must abide by the laws, regulations and rules of the state, local authorities and the construction site, and Party B shall bear all responsibilities for any violation.
3. Fighting is strictly prohibited on the construction site. All the consequences arising therefrom shall be borne by Party B, and those with serious circumstances shall be sent to the local public security organ for handling.
Eight. Other requirements
1. All construction tools and mechanical equipment shall be provided by Party B. ..
2. Party B should take care of itself.
3. It is forbidden to stop work during normal construction days, otherwise Party A has the right to change the construction team, and all expenses incurred during this period shall be borne by Party B. ..
4. During the construction process, Party B must assign special personnel to guard the site and fulfill Party B's obligations, otherwise Party A has the right to change the construction team, and all expenses incurred during this period shall be borne by Party B. ..
5. Party B shall not subcontract, otherwise Party A has the right to change the construction team, and all expenses incurred during this period shall be borne by Party B. ..
6, it is forbidden to waste materials, the rest of the construction of more than ≥50cm steel (welding) must be used in the appropriate parts.
IX. Validity of the Contract
This contract is made in duplicate, one for each party, and shall come into effect after being signed and sealed. After the content of this contract is completed, Party A withdraws the contract, and this contract will automatically become invalid.
Party A: _ _ _ _ _ _ Party B: _ _ _ _ _ _
_ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _
Construction project contract 4
Employer: _ _ _ _ _ _ (hereinafter referred to as Party A)
Contractor: _ _ _ _ _ _ (hereinafter referred to as Party B)
According to People's Republic of China (PRC) Contract Law, People's Republic of China (PRC) Construction Law, Regulations on Construction and Installation Contract and other relevant laws and local administrative regulations, combined with the relevant regulations of the company and the specific conditions of this project, Party A and Party B sign this contract through consultation.
Article 1 General situation of the project
1, project name: _ _ _ _ _ _
2. Project location: _ _ _ _ _ _
3. Structure type: _ _ _ _ _ _
4. Construction scale: _ _ _ _ _ _
Article 2 Subcontract Project Content and Unit Price
All the construction scope of an outer frame, the garage shall be less than 0.000 yuan/㎡, and the main building shall be calculated according to the construction area of more than 0.000 yuan/㎡ (when the outer cantilever frame is dismantled, the tower crane shall be dismantled).
Article 3 Scope of Contract
All the construction contents of the outer frame included in the construction drawings, all materials used for construction (including safety belts, helmets, safety and civilized construction signs, scaffolding, fastener leasing, safety nets, hard protective scaffolding and other equipment related to the outer frame), and the construction of pedestrian safety passages and temporary construction passages on the floors.
Article 4 Method of settlement
4. 1 The project payment is calculated according to the construction area.
4.2 Calculation of engineering quantity: According to the construction drawings, it is calculated according to GB/T503532005.
4.3 If there are changes due to the construction drawing or design, or the owner's reasons, and the labor cost is less than 65,438+0,000 yuan, it will not be adjusted; ()> 1000 yuan or more, settled according to the facts. Each expense must have a change notice, which can only be adjusted after the relevant personnel and the project manager sign it. Otherwise, it cannot be adjusted.
4.4 In principle, there will be no visa timing problem in this project.
Article 5 Requirements for construction progress and time limit for a project
The specific time is _ _ _ months according to Party A's requirements, and the specific node assessment cycle is subject to the node cycle signed by Party A and the construction unit, specifically:
Basic _ _ _ _ months
Theme _ _ _ _ months
_ _ _ _ months of decoration and renovation works
In case of work stoppage due to Party A's reasons, no slowdown fee will be charged for five consecutive days (including five days), and all fees (labor, materials and machinery) will be charged for more than five days, subject to the on-site visa confirmation, and the labor fee will be calculated according to the average worker 80 yuan/day and mechanic 120 yuan/day; The construction period is postponed. Failure to meet the above standards will not be postponed and the expenses will not be borne. If the construction period cannot be realized or the progress of Party B is affected due to Party B's reasons, Party B shall be responsible for the losses caused thereby.
Article 6 Construction Conditions and Requirements
6. 1 party b must carry out the construction in strict accordance with the national standards, the work instructions for sub-projects formulated by the project department, the construction operation procedures and the construction acceptance specifications.
6.2 In the process of construction, the operation must be carried out in strict accordance with the relevant construction drawings and technical disclosure.
6.3 All subdivisions of the project contracted by Party B must meet the qualified standards. Unqualified and potential quality hazards are not allowed to enter the next working procedure. The rework and material loss caused by Party B's own operation shall be borne by Party B, and double indemnity shall be conducted according to relevant regulations. If the project quality does not meet the design and specification requirements, the local rectification plan shall be implemented according to the company's regulations.
6.4 During the construction period, Party B shall ensure that the quality of the construction project reaches the standard at one time. For each violation, Party A has the right to give 200 yuan a fine and double the compensation for material losses.
6.5 Party B must organize personnel to seriously study the Regulations on the Administration of Work Safety in Construction Projects, and carry out the construction in strict accordance with the specification requirements and safety operation procedures, so as to achieve a safe, civilized and standardized site; Specifically, the builder and safety officer shall make safety technical disclosure in written form.
6.6 During the construction, Party B is prohibited from operating illegally to prevent casualties; In case of any safety accident due to violation of safety operation and rules and regulations, Party B shall be responsible for the industrial accidents below 200 million yuan, and 80% of the industrial accidents above 200 million yuan shall be solved by Party A and 20% by Party B..
6.7 The operating personnel of Party B's special specialty must hold the work license and do the occupational protection for special projects to prevent the occurrence of occupational diseases. The consequences caused by unlicensed and illegal operation shall be borne by Party B. At the same time, Party A will impose a fine of 500 yuan/person on Party B, and unconditionally bear the fine imposed on Party A by the construction and relevant departments.
6.8 Party B shall actively cooperate with the quality and safety inspection station to guide Party A's project and eliminate potential safety hazards in time.
6.9 The on-site construction personnel to which Party B belongs must abide by the regulations on on-site public security management and actively cooperate with the local police station to strengthen personnel management. In case of public security or criminal cases, Party B shall bear the management responsibility; Foreign or irrelevant personnel and their families shall not be brought into the construction site, and Party B shall be responsible for the safety accidents caused thereby. At the same time, Party A will impose a fine of 1 1,000 yuan on Party B, and unconditionally bear the fine imposed on Party A by the construction party and relevant departments.
6. 10 Party B is responsible for handling all kinds of certificates and procedures required by the state for the floating population to enter the site.
6. 1 1 Party B's admission personnel must wear qualified safety helmets correctly, use the "three treasures" of safety correctly, and equip necessary safety protection articles and facilities according to the working environment. Party A has the right to impose a fine of RMB 0/00 per person.
6. 12 It is forbidden to connect the power supply privately or use all kinds of electrical equipment illegally. If found, the penalty shall be 500 yuan/time.
6. 13 shall not damage the safety facilities and equipment, and 500 yuan shall be punished for each discovery.
6. 14 party b must designate a special person to be responsible for the safe and civilized construction, and set up fixed personnel to carry out cleaning, material stacking and site cleaning.
6. 15 The construction materials used by Party B must be classified and neatly stacked at the designated place as required, and cleaned up in time during the construction to ensure that the site is cleaned up by people as much as possible. Put an end to wasting materials and intentionally damaging materials, finished products and semi-finished products on the construction site. In case of violation, Party B shall pay Party A the liquidated damages for material abandonment according to the value of the abandoned materials, and bear all other expenses. Party B's own construction machines and tools must have factory certificates.
6. 16 The construction site and living area where Party B is located shall be kept clean and refreshing, and it is strictly forbidden to dump construction waste, domestic waste and meals. Otherwise, Party A has the right to pay Party B a fine of 200 yuan/person.
6. 17 fighting and stealing property are strictly prohibited on the construction site. In case of violation of regulations, Party A has the right to pay Party B a fine of 5,000 yuan. If the management of Party B participates in the fight, the punishment will be doubled, and if the circumstances are serious, it will be sent to the local public security organ for handling.
6. 18 carry out standardized and civilized construction according to the site, meet the requirements of standardized and civilized construction site, and pass the acceptance.
Article 7 Main work contents and requirements
7. 1 All cantilever scaffolding and daily maintenance required for the actual site of this project must conform to the construction scheme and safety measures. Measures to seize the construction period and civilized construction. The subcontractor's construction requirements for erection of all cantilever scaffolding at one time are reasonable, excluding multiple erection and demolition (except for special circumstances: it needs to be dismantled and then restored due to Party B's reasons).
7.2 The erection and dismantling of external scaffolding shall conform to the relevant structural requirements in Technical Specification for Safety of Fastening Steel Pipe Scaffolding in Building Construction (JGGG130-2001), and special scaffolding or super-high scaffolding shall be erected according to the special engineering scheme.
7.3 Daily maintenance, repeated erection and removal of various protective frames and protective measures required for foundation, main body, decoration and construction site (including: mechanical equipment such as four ports and five temporary facilities, mixers, portal frames, construction elevators, tower cranes and attached wells, and advertisements).
7.4 Installation and removal of all safe passages and platforms, and installation and removal of scaffolding for elevator installation.
7.5 Erection, arrangement and removal of safety net, dense mesh safety net and surrounding unloading operation platform.
7.6 Assembly and disassembly of shuttle grooves of upper and lower feeding platforms.
7.7 All outer frames and protective frames shall be painted as required by Party A, and Party B shall arrange two scaffolders to be responsible for the daily inspection and maintenance of scaffolding and safety nets.
7.8 It is required to meet the on-site acceptance standard and the acceptance conditions of Suining safe and civilized construction site, and it is qualified.
Article 8 Project Quality Acceptance and Payment Method
8. 1 It must meet the requirements of the current national standard "Quality Inspection and Judgment of Construction and Installation Works" and national mandatory provisions, and reach the standard of household acceptance.
8.2 Payment must be combined with quality inspection results.
8.3 The measured quality of subdivisional work shall be measured by the responsible foreman, quality inspector, technical director and safety officer according to the construction drawings and quality standards, specifications and evaluation methods, which shall be signed by the project manager as the basis for engineering quality evaluation, and the division and unit projects shall be based on the evaluation of supervision and quality supervision departments.
8.4 Payment method: Party B meets Party A's requirements in terms of project progress, quality, safety, civilized construction and coordination, and Party A pays in the following proportion:
8.5 70% of single qualified quantities shall be paid for concrete pouring from basement to 0.000 floor;
8.6 70% of the single qualified quantity shall be paid for the concrete pouring of the first floor of the main project;
8.7 70% of the single qualified quantity shall be paid for the concrete pouring of the first floor of the main project;
8.8 Pay 90% of the qualified quantities after the completion acceptance of the main body of the project;
8.9 100% of the total project cost shall be paid within three months after all outer frames are removed and transported away from the site.
Article 9 responsibilities of both parties
9. 1 Party B must obey the management of Party A, the supervisor and the project department.
9.2 If Party B really fails to guarantee the construction progress, project quality and safe production, and violates organizational discipline, and the score of safe and civilized construction fails to meet the standards promised by Party B, Party A will punish Party B 2000 yuan/time.
9.3 If Party B fails to carry out the construction according to the requirements of time limit, quality, safety and civilization agreed in the contract (including non-compliance with site management requirements), and Party A fails to make rectification within the time limit after notifying Party B in writing, Party A has the right to select another construction team for the sub-project or part of the single project, and all expenses arising therefrom will be deducted twice according to the amount incurred, and Party B shall unconditionally obey. In addition, the losses caused to Party A due to Party B's breach of contract shall be 10% of the total price as liquidated damages.
9.4 If Party B abandons the contract or subcontracts the project to a third party, Party A has the right to terminate the contract, and Party B shall bear all the economic losses of Party A. ..
9.5 If Party B gathers people to make trouble without reason, drives up prices, extorts labor fees, disturbs the normal working order of Party A, and causes accidents or construction accidents in Party A's office, resulting in adverse social impact and news exposure, Party A will fine Party B 50,000 yuan each time.
9.6. After Party A pays the progress payment to Party B in full according to this agreement, Party B shall pay the wages of migrant workers in full on time. In case of media exposure, migrant workers' petition or government intervention due to wage arrears, Party B shall compensate Party A with a penalty of 50,000 yuan each time and bear all economic losses. Party A may directly deduct the above money or expenses from Party B's project payment.
9.7 In addition to the actual economic losses caused to Party A by Party B's construction quality problems, compensation shall be made according to Party A's actual economic losses. ..
9.8 All kinds of fines and breach of contract shall be confirmed by Party A to Party B in written form. If there is any objection, Party A and Party B shall handle it through negotiation. If Party B does not accept or reject Party A's notice, Party A shall submit the written penalty and default form to the company's finance as the basis for deduction within 3 days.
9.9 Party B shall cooperate with Party A unconditionally and free of charge to handle relevant construction procedures, so that the project can proceed as planned.
9. 10 Party B shall handle and arrange the quality supervision station, safety supervision station, inspection and project acceptance during the project construction, and notify Party A for assistance in time.
Article 10 Other related matters
10. 1 Both parties agree that the performance bond of RMB 10,000.00 Yuan shall be paid by Party B and shall come into effect after being signed by both parties. This contract shall be terminated after the first payment of the progress payment and the completion of all obligations under this contract by both parties, and the deposit shall be returned in one lump sum. Party B must hold this contract to settle the balance of the project, and this contract will automatically become invalid after the balance of the project is settled.
10.2 matters not covered in this contract shall be settled by both parties through consultation, and relevant agreements or annexes signed by both parties shall have the same effect as this contract after being supervised by both parties.
10.3 Any dispute arising from the performance of this contract shall be settled by both parties through consultation. If negotiation fails, a lawsuit may be brought to the people's court where the project is located.
10.4 Various schemes, plans, guarantees and letters of commitment provided by Party B to Party A are automatically attached to this contract and have the same legal effect as this contract.
10.5 This contract is made in quadruplicate, three for Party A and one for Party B. This contract shall come into effect after signing the construction safety agreement and the responsibility letter for site safety and civilized construction, paying the performance bond, and being signed and sealed by the legal representative or legal representative.
Employer (seal) _ _ _ _ _ _ Contractor (seal) _ _ _ _ _ _ _
Principal (signature): _ _ _ _ Principal (signature): _ _ _ _ _ _
Site leader (signature): _ _ _ _ _ Site leader (signature): _ _ _ _ _
ID number: _ _ _ _ _ ID number: _ _ _ _ _ _
Tel: _ _ _ _ _ Tel: _ _ _ _ _ _
_ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _
Construction project contract 5
Party A (responsible person): _ _ _ _ _ _ _
Party B (intermediary): _ _ _ _ _ _ _
According to the provisions of the Contract Law of People's Republic of China (PRC), Party A and Party B, based on the principles of equality, voluntariness and equal compensation, have reached the following agreement through full consultation:
I. Entrusting matters
1. Entrusted by Party A, Party B is responsible for introducing Party A to directly negotiate with the construction unit of this project (hereinafter referred to as the project), providing Party A with important information about this project, and finally facilitating Party A to sign a contract with the construction unit on this project.
2. "Intermediary success" means that Party A and the construction unit sign a written project contract for this project.
Two. Obligations of Party A
1. Party A is responsible for providing true qualification certificates, business licenses and other relevant materials; Responsible for contract negotiation with the construction unit.
2. If the intermediary is successful, Party A will fully perform the construction contract signed with the construction unit. Party A's rights and obligations arising from the performance of the construction contract have nothing to do with Party B. ..
3. If the intermediary is successful, Party A shall pay the intermediary remuneration to Party B as agreed in this contract. If the payment is not made in time, Party B shall bear the penalty of% of the daily unpaid amount.
Three. Obligations of Party B
1. Party B must provide information about the project to Party A, and assist Party A to conduct on-the-spot investigation of the project.
2. Party B promises that the above information about this project provided to Party A is true and reliable.
3. In the process of contract negotiation between Party A and the construction unit, Party B, as an intermediary, shall perform the obligations of prudence and honesty.
Four, the calculation method, payment time and payment method of intermediary remuneration.
1. The intermediary remuneration of this project is _ _ _ _ _ _ _ _% of the total construction contract (that is, RMB _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _).
2. Intermediary remuneration settlement method:
The total remuneration of the intermediary is RMB _ _ _ _ _ _ _ ten thousand yuan. After Party A signs the project construction contract with the construction unit recommended by Party B, the construction unit will pay _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ After that, during the normal construction period of three months, Party A shall pay the balance of the agency fee to Party B, which can be transferred or paid in cash.
3. Party A can deposit or transfer the money into the account designated by Party B in the form of transfer or cash, or directly pay the cash to the agent designated by Party B. ..
Verb (abbreviation for verb) confidential matter
1. Both parties shall fully keep the business secrets involved in this agreement.
2. Both parties shall not use the business secrets obtained in the intermediary process to do anything that is not conducive to the other party, otherwise they have the right to ask the other party to bear the liability for breach of contract.
3. If Party A signs a construction contract with the owner in the name of related enterprises or local subsidiaries and all reinvestment companies established in Nanning, the intermediary has the right to require Party A to pay the intermediary remuneration according to the terms agreed in this contract.
Termination of intransitive verb contract
1. Party B fails to complete the intermediary task within _ _ _ _ _ _ _ _ years after the signing of this contract.
2. If the mediation is successful, the rights and responsibilities of both parties to this contract will be fully fulfilled and terminated after the payment is completed.
3. When Party A and Party B agree to terminate this contract or other legal matters occur, this contract will be terminated.
Seven. Dispute resolution method
In case of any contract dispute, if negotiation fails, both parties agree to submit it to the arbitration commission of the place where the contract is signed for arbitration.
Eight. any other business
1. Party B shall not delegate the matters entrusted in this contract.
2. This contract is made in two originals, one for each party, and shall come into effect after being signed and sealed by both parties.
3. The blank parts of all horizontal lines in this contract are voluntarily filled in by the representatives of both parties, which is true and effective.
Party A (official seal): _ _ _ _ Party B (official seal): _ _ _ _ _
Legal representative (signature): _ _ _ _ _ Legal representative (signature): _ _ _ _ _
_ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _
Construction contract template (5 samples) related articles:
★ The latest 5 templates of simple building contract.
★ 5 samples of simple project contract
★ 5 copies of model construction contract.
★ Five Excellent Templates for Engineering Construction Contract in 2022
★ The contract template for individual contracted projects is 5 simple articles.
★ 5 standard individual project contract templates
★ 5 latest model contracts for private housing construction.
★ 10 project contract template
★ 5 contract document templates.
★ Model construction contract of building engineering (5 selected articles)