Model contract for landscape greening construction 1
Contract number:
Party A:
Legal representative:
Registered address:
Contact telephone number:
Party B:
Legal representative:
Registered address:
Contact number
According to the Contract Law of People's Republic of China (PRC), the Construction Law of People's Republic of China (PRC) and other relevant laws and regulations, Party A and Party B have reached an agreement on the construction of landscape greening project through friendly negotiation and agreed to sign this contract for mutual compliance.
Article 1 General situation of the project
1. 1 project name: landscape greening project construction.
1.2 Project location:.
1.3 project scope: group garden landscape greening project construction, see landscape construction drawing for details.
1.4 project content
1.4. 1 Landscaping project: mainly including site restoration, leveling, shaping and planting.
Fine soil planting, fertilization, transportation, planting, support, shaping and maintenance of seedlings and flowers (from the date of completion acceptance), and site cleaning. Party A shall ensure that there is enough planting soil on site.
1.5 construction period
1.5. 1 start date:.
1.5.2 completion date:.
Article 2 Contract Price and Payment Method
2. 1 The total construction contract price of this project is always RMB Yuan only (including tax), in figures: RMB Yuan. Calculate the price temporarily according to the existing construction drawing. If there is any design change, the settlement method shall be as stipulated in Article 3.
2.2 The cost of landscaping works adopts the quota comprehensive contract method, which consists of seedling price and comprehensive rate, and is based on the list of seedlings in the construction drawing and the unit price. The comprehensive total price includes seedling purchase price, transportation fee, seedling survival fee, planting and construction fee, water and electricity fee, seedling support fee, management fee, profit, fees, risk lump sum coefficient, taxes and other expenses needed to complete the project. The seedling price and its comprehensive rate are shown in the annex to the contract.
2.3 Party A shall pay 80% of the total project payment to Party B within 10 days after the project is completed and passed the completion acceptance ... After Party A completes the handover procedures of the completion data and checks the settlement, it shall pay 95% of the total project settlement price, and the rest shall be used as the quality guarantee, with a warranty period of 12 months. After the warranty period expires, it will be paid in one lump sum (interest-free) after acceptance.
2.4 All project funds stipulated in this contract shall be paid in RMB to the account designated by Party B..
Before accepting the project payment, Party B shall issue to Party A the same legal invoice issued by the local tax department of the project;
2.5 Within 10 days after the project completion acceptance, Party B shall submit qualified project completion documents and project settlement data for Party A's review, and Party A shall complete the review within 30 working days after receiving Party B's complete data, and complete the settlement with Party B within 15 working days after the review is completed.
Article 3 Project Settlement
3. 1 During the construction process, the part that needs to be changed due to Party A's reasons or design requirements shall be regarded as design change. The nursery stock price adopts the nursery stock list price and the visa price approved by Party A, and the comprehensive rate is 38%.
3.2 Project completion settlement fee composition:
3.2. 1 total contract price of construction drawing content;
3.2.2 Visa fees incurred by Party A due to design changes.
Article 4 Engineering Quality and Technical Requirements
4. 1 Party B shall carry out the construction with good quality and quantity in strict accordance with the drawings, predetermined scheme and bill of quantities approved by Party A, and complete it on time and submit it to Party A for acceptance.
4.2 The seedlings have beautiful tree shape, good growth and no pests and diseases. The foreign seedlings shall show quarantine certificates, and the survival rate of seedlings shall reach 1OO% at the time of acceptance, and the landscape effect shall meet the requirements of Party A. The survival guarantee period of all seedlings is 12 months. If the seedlings tilt or die during this period, Party B shall support and replant the seedlings within 65,438+00 days from the date of Party A's notice. From the date when Party A accepts reseeding, the survival guarantee period of the seedlings supported by reseeding is 12 months, and all expenses incurred by reseeding shall be borne by Party B. ..
4.3 The specifications and forms of seedlings must be verified by the landscape engineer of Party A, otherwise Party A has the right to request replacement. In case of special circumstances, the seedlings can only be planted with the consent of Party A and the landscape design unit. For the main landscape trees (main landscape nodes) in special locations and relatively important tall trees, the construction unit must take photos, number and record them before arriving at the site and submit them to Party A for confirmation, so that Party A can choose and put them on record.
4.4 The soil for planting seedlings should be nutrient-rich soil suitable for the growth of corresponding seedlings. When the trees enter the site, the specifications of the soil ball shall conform to the Code for Construction and Acceptance of Urban Greening Projects (CJJ/T82-99). If the soil conditions for planting trees are not good, you need to change the soil. When planting shrubs, it is necessary to ensure that the planting soil with a thickness of 40CM is better.
Article 5 Acceptance Criteria
5. 1 after receiving the written notice from party b, party a shall conduct the acceptance within 7 days (in case of special circumstances, it shall notify party b).
5.2 Acceptance criteria: The specifications of trees and middle and lower shrubs shall be accepted according to the dimensions specified in the design drawings, and the trees shall be cooked. For seedlings smaller than the specifications required by the drawings, the actual specifications shall prevail; The seedlings whose specifications are greater than the requirements of the drawings shall be subject to the actual acceptance specifications after being approved by the site management personnel of Party A; Otherwise, it shall be accepted as drawings and specifications; If one of the width and height of the road arch does not meet the drawing specifications, the settlement shall be based on the principle of the lower. If Party B changes the varieties and specifications of seedlings, Party A has the right to ask Party B to change them unconditionally within three days, and Party B shall pay a penalty of twice the stipulated unit price of seedlings, and shall also be liable for compensation if losses are caused to Party A.. ..
5.3 DBH: (trunk diameter): refers to the diameter of the trunk at 1.2m above the ground. Crown width: refers to the diameter of the vertical projection plane of the crown. Tree height: refers to the vertical height from the ground to the top of normal growing seedlings.
5.4 After the seedlings are purchased and planted, Party B shall submit the seedling purchase acceptance form and detailed information to Party A for settlement review.
5.5 If seedling size entered by Party B is not within the scope of the list, and the nursery stock prices are 12 ~ l3CM and 14 ~ 16cm, the site acceptance is between 13 ~ 14cm, and the settlement shall be subject to l3CM.
5.6 Before the concealed works are covered, they shall be reported to Party A's representative for acceptance 24 hours in advance, and can only be covered if they are qualified. If Party A's representative fails to check and accept on time, Party B has the right to make up for it. Party A has the right to re-examine the covered concealed works. If the inspection is unqualified, the inspection and rework expenses shall be borne by Party B; If the inspection is qualified, the corresponding expenses shall be borne by Party A. ..
Article 6 Safe and civilized construction
6. 1 During the construction period, Party B shall conduct civilized construction, take corresponding measures and take safety precautions.
6.2 During the construction period, it is forbidden for Party B's personnel to fight and gather people to gamble. In case of the above situation, Party A has the right to unilaterally terminate the contract and choose other construction teams to carry out the construction, and the expenses and losses caused to Party A therefrom shall be borne by Party B. ..
6.3 During the construction period, any safety accident or civil dispute between Party B and any third party due to Party B's fault shall be borne by Party B. ..
6.4 During the construction, Party B shall ensure that the site is clean and tidy, and deal with the engineering garbage in time, which will not affect the normal living order and ecological environment of the surrounding residents.
Article 7 Rights and obligations of both parties
7. 1 Rights and obligations of Party A
7. 1. 1 Party A designates the person in charge of the project site to be fully responsible for all the work of the project. The data and documents related to the project are deemed to be approved by Party A after being signed by Party A, and all its actions are the true expression of Party A's will, which will be approved by Party A.. ..
7. 1.2 Organize the design unit to conduct joint review of construction drawing disclosure with Party B, provide survey baselines and leveling points, and provide construction drawing sets and general plan sets.
7. 1.3 Party A shall provide the on-site water and electricity interface to the place agreed by both parties.
7. 1.4 The landscape engineer of Party A shall supervise the whole process of seedling planting quality, and have the right to propose any rectification measures to Party B if it is found that it does not meet the requirements.
7. 1.5 During the construction process, Party A has the right to adjust and redistribute Party B's construction scope according to factors such as Party B's project progress, cooperation with Party A and seedling quality.
7. 1.6 Pay the contract price on time as agreed in the contract.
7.2 Rights and obligations of Party B
7.2. 1 Before starting work, Party A must provide the list of personnel stationed at the construction site and relevant certificates, which are consistent. Party B is designated as the person in charge of the project site and is fully responsible for all the work of the project. The materials and documents related to this project are deemed to be approved by Party B after being signed by Party B, and all their actions are the expression of Party B's true meaning and should be approved by Party B. Party B shall not change the person in charge of the site without authorization. In case of special circumstances, Party B shall notify Party A in writing, and it can only be changed after Party A agrees. However, all the actions before the change are still the true intention of Party B, and Party B agrees. The person in charge of Party B's site must ensure the attendance rate is above 80%, and other management personnel must ensure the attendance rate is above 90%.
7.2.2 Party A may provide Party B with the latest information needed for construction, and Party B shall adjust the construction plan according to the latest information and site conditions.
7.2.3 Party A shall assist Party B in handling the formalities of urban management, sanitation, family planning, municipal transportation and other departments related to the project, and the expenses shall be borne by Party B;
7.2.4 For the water and electricity metering used by Party B during construction and maintenance (the difference between the summary table and the summary table shall be shared by all construction units), Party A shall charge the water and electricity fee according to the actual market price and deduct it when paying the project payment.
7.2.5 Party B shall promptly clean up the construction waste within the scope of its contracted projects. If the improvement is not made after Party A's written notice, Party B will bear the penalty of double the cleaning fee.
7.2.6 Before Party A's acceptance is completed, all finished and semi-finished products of the project shall be kept by Party B, and the risks and expenses arising therefrom shall be borne by Party B. ..
7.2.7 In the process of engineering construction, a reasonable construction operation plan must be adopted and an appropriate mode of transportation must be selected. All kinds of underground pipelines, roads, overhead power supplies, communication lines and other buildings and plants shall not be damaged, and disputes and expenses arising from damage to related objects shall be borne by Party B. ..
7.2.8 During the construction process, due to Party A's use or sales needs, the adjustment of construction period of local units and the construction at the junction of each bid section are not calculated separately, regardless of whether there is cross-construction influence or mutual cooperation. If the construction period is affected, the construction period will be postponed accordingly with the consent of both parties.
7.2.9 In the process of construction, the power lines must be connected from the temporary power distribution room on the construction site in accordance with the requirements of the state on safe and civilized construction, so as to ensure the lighting for night construction.
Article 8 Liability for breach of contract
8. 1 If there is a dispute between Party B and migrant workers (such as wage arrears for migrant workers), and Party A thinks that it will damage Party A's reputation, Party A has the right to settle it first according to the requirements of migrant workers, and deduct all the expenses incurred from Party B's contract payment. If the above amount is still insufficient to make up for Party A's losses, Party A has the right to claim compensation from Party B. ..
8.2 If the project is not completed within the contract period, Party B shall pay a penalty of RMB/day to Party A for each day of delay (unless the delay is agreed by Party A); If the delay exceeds days, Party A has the right to terminate the contract unilaterally.
8.3 During the construction period, Party B must obey the management and arrangement of Party A, and cooperate closely with other professional contractors, and shall not pass the buck, otherwise Party A has the right to terminate the contract.
8.4 If Party B's project manager is incompetent, Party A has the right to ask Party B to replace it, and Party B shall replace it within one week. If Party B refuses to replace it, Party A has the right to terminate the contract.
8.5 Under any of the following circumstances, if the written warning of Party A fails, Party A has the right to terminate this contract:
8.5. 1 The terrain treatment within the construction scope of Party B cannot meet the requirements.
8.5.2 The construction waste generated by Party B within the construction scope of this contract has not been removed or transported to the place designated by Party A. ..
8.5.3 If the project fails to be completed according to the construction schedule due to reasons other than Party A's, it has not been changed within one week after being notified by Party A in writing.
8.6 Subcontracting of this project is prohibited, otherwise Party A has the right to terminate the contract, and all losses caused thereby shall be borne by Party B..
8.7 After Party A exercises the unilateral rescission right according to this contract, Party A is only entitled to make settlement according to 90% of the qualified engineering quantity audited and signed by Party A, and the remaining amount is regarded as the liquidated damages paid by Party B to Party A; Where Party A suffers losses due to the termination of this Contract,
Party B shall also be liable for compensation.
8.8 If Party A fails to pay the project payment on time according to the payment method stipulated in the contract, Party A shall pay Party B a penalty of 5‰ for each day overdue; If Party B delays or stops work, Party A shall bear all responsibilities and related expenses. If the overdue period exceeds 10 working days, Party B has the right to terminate this contract.
Article 9 Ways to resolve contract disputes
Any dispute between Party A and Party B during the performance of this contract shall be settled through negotiation. If negotiation fails, the following methods shall be selected: ① bring a lawsuit to the court where Party A's unit is located; (2) Arbitration shall be conducted by an arbitration institution. (Note: The Legal Affairs Department determines a jurisdiction clause according to the actual situation of the contract. Regardless of litigation or arbitration, the court or arbitration institution nearest to Party A shall be selected. If the arbitration method is selected, the name of the institution must be accurate and conform to the relevant provisions of the Arbitration Law. )
Article 10 Others
10. 1 The mailing address of the "written notice" clause in this contract shall be based on the address written by Party B on the first page of this contract. If the address is changed, Party B shall notify Party A in writing within days from the date of change, otherwise the letter sent by Party A at this address shall be deemed as delivered.
10.2 The bidding documents for this project, as well as supplementary documents related to the contract, bill of quantities, drawings and memoranda signed by both parties, are all annexes to the contract and have the same effect as the contract.
10.3 during the contract period or after the termination of the contract, confidential information related to this project and the contract business shall not be disclosed without the consent of the relevant parties.
10.4 this contract is made in sextuplicate, with party a holding four copies and party b holding two copies, all of which have the same effect, and shall come into force after being signed and sealed by both parties.
Party A (seal):
Legal representative:
Date of signing:
Signing place:
Date Party B (Seal): Legal Representative: Date
Model essay on landscaping construction contract II
Employer: (hereinafter referred to as Party A)
Contractor: (hereinafter referred to as Party B)
In accordance with the Contract Law of People's Republic of China (PRC) and other relevant regulations, both parties, following the principles of equality, voluntariness, fairness, honesty and credibility, signed this contract on the greening project of Jinxiu Jiangnan Community through consultation:
I. Overview of the Project:
1, project name:;
2. Project address:;
3. Project content:.
Second, the scope of contracting:
Greening and landscape (including: waterscape, garden road, pavilion, sidewalk and greening water, electrical installation, earthwork, etc.). ) The first, second and third phases of the construction of Jinxiu Jiangnan Community;
Third, the way of contracting and settlement:
1. Contracting method: this project adopts the form of contracting for work and materials.
2, the contract project cost settlement method:
(1) The greening and landscape engineering of residential areas shall be based on the quota of 94 ancient gardens in Zhejiang Province, and the quantities shall be settled according to the actual conditions.
The contract cost of landscaping works = direct cost of landscaping works+12%× direct cost of landscaping works+price difference of main materials ×3.24%. The unit price of seedlings is based on the online quotation of Huangchuan seedling base in Henan Province during the construction period, and the price of landscape engineering building materials is based on the market price (including tax) in the middle of each month during the construction period. Cement is added with 65438+ on the basis of purchase price. For sub-projects not included in the garden quota, Zhejiang 94 civil engineering quota shall be applied first, and then ancient construction quota shall be applied.
2, seedling maintenance for two years requires the survival rate of 100%, and the seedling maintenance fee is calculated at 10% of the annual direct fee for seedlings.
3. Payment method:
(1) Payment method of the first phase of project payment: within 10 days after the contractor completes the first phase of landscape greening project, the employer shall pay the contractor 30% of the completed project cost. The Employer shall pay 30% of the first phase project cost 10 days after the second phase greening landscape project starts; Pay 35% of the cost of the first phase project within 10 days after the start of the third phase project, and pay 5% after the acceptance of the third phase project.
(2) Payment method for the second phase project: The contractor shall pay 70% of the second phase project cost after the landscape greening project is completed, 65,438+05% of the second phase project cost after the third phase project starts 65,438+00 days, 65,438+00% of the second phase project cost after the third phase project acceptance, and 5% after the third phase project acceptance one year.
(3) Payment method of the third phase project: The contractor will pay 70% of the third phase project cost after the completion of the third phase landscape greening project, 25% after the settlement audit, and 5% after the acceptance of the third phase project for two years.
(4) After the project is completed and accepted, the contractor shall submit the completion drawings and settlement report, and the employer shall complete the audit within three months.
Fourth, the time limit for a project:
The construction period of the first phase of the project is 60 days, subject to the commencement report, and the second and third phases of the project are decided by both parties through consultation.
Verb (short for verb) quality:
The quality of the project must be carried out in accordance with the design drawings and the current national codes and standards, and at the same time, it must reach the technical level of the landscaping project in Zhengzhou Greentown Community. If this level cannot be reached, a penalty of 5% of the project cost will be deducted.
Six, security:
The construction site of this project shall implement the Standard for Safety Inspection of Building Construction (JGJ59-99). The contractor must, in accordance with the relevant provisions of the state, conscientiously implement various safety technical measures to ensure safe production and civilized construction on the construction site. Personal injury, property loss and all other accidents caused by the contractor during the construction shall be borne by the contractor.
Seven. any other business
1. If the Employer fails to make payment according to the contract within one year after the project review, the house shall be used as payment.
2. If the contractor fails to carry out the construction according to the contract or the acceptance is unqualified, the employer refuses to pay 20% of the completed project payment.
3. Disputes arising from the performance of this contract can be settled by both parties through consultation; If negotiation fails, either party may bring a lawsuit to the people's court with jurisdiction at the other party's domicile.
This contract is made in quadruplicate, with each party holding two copies. Matters not covered in this contract shall be settled by both parties through consultation.
Sender: (Seal) Organizer: (Seal) Legal Representative: Legal Representative: Client: Client: Signature Time: Signature Time:
Model contract for landscaping construction 3
Employer (Party A): _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _
Legal Representative: _ _ _ _ _ _ _ _ _ _ _ Tel: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _
Legal Representative: _ _ _ _ _ _ _ _ _ _ _ Tel: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _
A, the construction site:
2. Cost of greening project: _ _ _ _ _ _ _ _ _ _ _ _ _ _ (in words)
Three. Time limit for a project When Party A makes full preparations for Party B, it shall ensure the speed of the time limit for a project as soon as possible.
Four. Preparation for commencement: Party A shall meet the corresponding requirements of Party B before commencement.
Verb (abbreviation of verb) Party A confirms the appointment of _ _ _ _ _ _ _ _ as the representative of Party A, who is responsible for supervising Party B's construction and fully handling related matters.
VI. Payment Method of the Project:
40% of the total project price shall be paid as the start-up fund of Party B within 2-5 days after the project starts ... 50% of the total project price shall be paid after Party A's acceptance of the later project, and 65,438+00% of the final payment shall be settled after the completion and maintenance of the project for one week.
7. Project quality: The planted seedlings must meet the requirements of the project, and the construction shall be conducted by both parties through consultation, and the varieties, specifications and cultivation quality of the seedlings shall not be changed.
Eight. This contract shall come into force after being signed (sealed) by both parties and shall have legal effect. After completion and settlement, this contract will be automatically terminated after Party A pays and Party B delivers the project to Party A. ..
Nine: This contract is made in duplicate, each of which has the same legal effect. After both parties sign (seal), each party holds one copy.
X. Matters not covered in this contract shall be settled by both parties through consultation.
Party A: _ _ _ _ _ _ _
Party B: _ _ _ _ _ _
Date of signing the contract: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _.
Contract signing place: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _
202 1 related articles on contract template of landscape greening construction;
★ 202 1 simple greening project contract template
★ 202 1 year afforestation contract model
★ 202 1 simple greening contract mode
★ 202 1 year construction contract template
★ There are 3 latest model articles on greening maintenance contract, 202 1.
★ 202 1 year site contract template
★ 3 Model clauses of landscape greening construction contract
★ 202 1 model project contract
★ 202 1 year simple engineering contract template
★ Model greening project contract