Party A: Party B:

In order to ensure the smooth progress of the project construction, Party A and Party B, through consultation, have reached the following sub-contract terms for the sub-project construction:

A, engineering subcontracting:

1, project name:

2. Building area: square meters;

3, the subcontract content:

4. Contract price: this contract is in the form of fixed unit price contract, that is, the labor cost is RMB/m2;

5. Quality requirements: meet the requirements of national standards;

6. Allocation method:

Two. Party A's responsibilities

1, responsible for the examination and approval procedures before construction to ensure the normal construction;

2, responsible for coordinating the relationship with construction, supervision, quality supervision, safety production management and other departments;

3, responsible for the development of civilized construction on the construction site, project quality, safety in production, project progress and other aspects of the management system and comprehensive coordination management;

4. Responsible for personal accident insurance for all personnel on the construction site, and responsible for supervising and inspecting the use of labor protection articles by workers;

5. Be responsible for the safety education and training of all construction personnel entering the construction site, and supervise the construction personnel in accordance with the construction operation procedures;

6, responsible for engineering construction scheduling, coordinate the relationship between each type of work, to ensure the orderly construction;

7, responsible for the unified management of construction personnel, all construction personnel must dress neatly. Have the right to punish subcontracting teams and individuals who do not obey management;

8. Have the right to manage the subcontractors who fail to pay the service fees according to the regulations, and directly pay the service fees for individuals.

Three. Party B is responsible for

1, the construction must be carried out in accordance with the requirements of relevant specifications, and the problems found by the construction unit and the superior competent department should be rectified in time, and the expenses arising therefrom shall be borne by the construction unit;

2. According to Party A's requirements, organize construction personnel to enter the construction site in time;

3, responsible for the daily construction task deployment of safety education for construction personnel;

4. Responsible for distributing uniform clothes for construction personnel and providing qualified safety helmets for each construction personnel;

5, responsible for checking the operation of the required mechanical equipment on duty, found the problem, report in time, to ensure that the equipment does not run in spite of illness;

6, responsible for the supervision and inspection of this type of work operators in accordance with the operating procedures for construction (special type of work operators who have the requirements of related certificates must hold relevant certificates), not barbaric construction, not drinking; Self-check the completed sub-projects every day to ensure one-time qualification;

7. Be responsible for the safety production and environmental sanitation management of the construction site of this type of work, store the surplus materials generated by the construction in a unified way according to the requirements of the project department, and clean up the action site in time.

8. Take full responsibility for production safety accidents of this type of work.

After the signing of the above contract, both parties shall earnestly perform it and have legal effect. Matters not covered in this contract shall be negotiated by both parties.

This contract is made in triplicate. Party A and Party B each hold one copy, and the other copy shall be submitted to the company for filing.

Party A (official seal): _ _ _ _ Party B (official seal): _ _ _ _ _

Legal representative (signature): _ _ _ _ _ Legal representative (signature): _ _ _ _ _

_ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

2. General Edition of Engineering Labor Contract Model

Party A: Party B:

In order to clarify the rights and obligations of both parties, this contract is hereby formulated through negotiation between Party A and Party B in accordance with the Contract Law of People's Republic of China (PRC), Regulations on Construction and Installation Engineering Contracts, Construction Engineering Contract (GF-1nine thousand nine hundred and ninety-nine-0201) and the National Regulations on the Management of Labor Contracts in Construction and Installation Engineering Market.

I. Project name:

1. Project location: residential project in xxx community (two high-rise residential buildings)

2. Project overview: about square meters (subject to the actual construction area).

3. Entry date (subject to the commencement date notified by Party A).

4. Form of contract: labor contract, non-governmental labor service.

Second, the contract content:

1. Main masons: brick masonry, mortar specimen making, indoor and outdoor decoration, ground (including floor tiles of public buildings, lintels for doors and windows of secondary constructional columns). All civil mud projects, such as roofing and apron (including all machines and tools for mud operation, mixers, mortar machines, trolleys, shovels, ash buckets, feet and other supplies).

2. Masonry project: indoor and outdoor infilled wall masonry and parapet sporadic masonry construction in this project.

3. Indoor plastering: wall plastering (including installation and galling of steel mesh, etc. ), after the installation of doors and windows plug plaster, etc.

4. Ground engineering: all contents included in the construction drawings of balcony, kitchen, bathroom, interior and podium (public walkways, stairs, etc.). ): Two grinding machines are subsidized for the covers and floor tiles decorated in public areas, hole filling and plastering of holes (excluding exterior wall paint, decoration and insulation layer).

5. After the construction of each type of work is completed, people will leave the site, be responsible for cleaning all floors, sweep the floor out of the house, and reach the delivery standard.

Third, the project contracting standards:

All the contracting scope of this project is contracted according to the contract: RMB/㎡ (calculated according to the construction area, the actual completed engineering quantity shall be settled by Party B in cooperation with Party A, and the final settlement data of both parties shall prevail. In principle, there will be no hourly workers. If the consent of Party A is obtained in advance for special reasons, the work shall be calculated in RMB/working day, and the coolies shall be settled in RMB/working day).

Four, according to the construction area of the following subdivisional work to pay the monthly progress payment:

1. Masonry works: RMB/㎡.

2. Internal plastering: RMB/㎡.

3. Plastering: RMB/m2

4. Floor: RMB/㎡.

5. Common parts and roof: RMB/㎡.

6. aproll: RMB/m2

Verb (abbreviation for verb) Terms of payment:

Party A shall pay Party B 85% of the daily progress payment of the project amount measured before 30th of each month, 85% of the project amount within 15 days of the following month, 95% of the project amount if the whole project passes the initial inspection, and the balance shall be paid within two months.

Intransitive verb deposit: When Party B voluntarily signs this contract, it shall pay Party A a project quality deposit of 200,000 yuan.

7. Refund of deposit: Party B will refund 50% after the structural brick body is completed, and all the rest will be refunded after plastering.

Eight. Party A's responsibilities:

1. Party A shall ensure that bricklayers will enter the site to lay bricks within 6 months from the date of signing the contract, otherwise, the deposit will be refunded to 200,000 yuan, and Party B will be compensated for liquidated damages of 60,000 yuan only.

2. Party A strictly implements the contract, and the project payment is in place on time.

3. Party A shall provide Party B with water and electricity for accommodation, canteen, office and staff.

4. Party A shall ensure that Party B's construction materials, construction machinery, cranes, mechanical operators and commanders are provided by Party A according to the equipment conditions, and Party B shall not bear the expenses.

Nine. Party B's responsibilities:

1. Party B's personnel must unconditionally obey the management of Party A's project manager and related management personnel and abide by Party A's rules and regulations. If they violate the rules and regulations of Party A, they will be responsible for the fine and they will be educated. In severe cases, they will quit the construction site.

2. Party B shall unconditionally and strictly implement Party A's technical requirements and drawings disclosure, strictly disclose and standardize the construction.

3. Party B's fine: The safety and quality problems raised by safety officers and quality inspectors shall be rectified and reworked unconditionally in time until they meet the requirements, and the materials required for rework shall be responsible for themselves.

4. Party B shall undertake on-site machine maintenance by itself.

5. Party B must meet the requirements of the project schedule, reasonably organize employees and arrange production.

6. During the main construction period, Party B shall have at least 2 site management personnel, including site project management personnel 1 person and construction lofting personnel 1 person.

7, warehouse management, living quarters, logistics, safety and civilized construction must be carried out in accordance with the relevant provisions of the company, to ensure that the site standards, won the city's safe and civilized construction site.

8. Party B must designate a special person to manage the safety production. If the safety accident within the scope contracted by Party B is less than 5,000 yuan, Party B shall be responsible for it; If it exceeds 5,000 yuan, except for the insurance company, Party A shall bear 80% of the normal compensation and Party B shall bear 20%.

9. Party B must do a good job in the maintenance of water and electricity, doors and windows, heating and ventilation, elevators, etc.

10. Party B shall be responsible for boiling water and hot water on its own, and provide necessary medicines for cooling summer heat and external first aid.

1 1. Party B is responsible for labor protection articles, helmets, safety belts, safety ropes, labor protection clothing, etc.

12. Party B shall be responsible for the lamps, wires, plug-boards, light bulbs and other supplies needed in the construction site.

X. Quality requirements and corresponding penalties:

1, strictly abide by the current national construction specifications and mandatory engineering construction specifications.

2, cast-in-place structure engineering, it is forbidden to appear hole phenomenon, a fine 200 yuan, shuttering process towel saw material, found a fine 100-200 yuan, and is responsible for the rectification to meet the quality requirements.

3, the main structure engineering quality must reach the city qualified structural engineering.

4, the project completion must reach a one-time acceptance notice. The first unqualified acceptance will be fined 1000 yuan, the second unqualified acceptance will be fined 3,000 yuan, and the third unqualified acceptance will be regarded as Party B's breach of contract.

XI。 Matters not covered in this contract shall be settled by both parties through consultation. Any dispute in the performance of the contract can be brought to the people's court and labor court where the project is located.

12. This contract is made in triplicate, with Party A holding one copy and Party B holding two copies. It takes effect after being signed by both parties, and both have the same legal effect.

Due to the change of drawing design, the cost within the construction area shall not exceed 1000 yuan, and the unit price of the project shall not be increased or decreased separately.

Party A (official seal): _ _ _ _ Party B (official seal): _ _ _ _ _

Legal representative (signature): _ _ _ _ _ Legal representative (signature): _ _ _ _ _

_ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

3. General Edition of Engineering Labor Contract Model

Party A: (hereinafter referred to as Party A) Party B: ID number: (hereinafter referred to as Party B)

Based on the principle of equality and mutual benefit, Party A and Party B have reached the following agreement (hereinafter referred to as the Agreement) on labor cooperation (hereinafter referred to as the Project) through friendly negotiation:

I. Location of labor service:

Second, the labor cost:

The service fee is tentatively set at RMB/day (in words: RMB), hereinafter referred to as service fee).

The service fee includes: accommodation, living expenses, domestic utilities, workers' accident insurance and all force majeure expenses.

Three. Labor service period:

The labor service period of Party B is tentatively set at months. (According to the requirements of Party A's construction progress plan), if the construction period needs to be extended due to Party A's request and written consent, the labor service period can be extended, and Party A will settle accounts and pay the labor service fees according to the facts during the extended period; In addition to the above reasons, Party B shall be responsible for the extension of the construction period and labor service period.

Four. Rights and obligations of Party A:

1. Be responsible for the overall management of Party B's labor service personnel, and supervise Party B's labor service progress, production quality, construction period, safety and civilized production;

2. Communicate, coordinate and handle daily affairs with the project supervisor and design unit;

3. Be responsible for the final audit of the labor workload provided by Party B, and pay the labor fee monthly according to the actual attendance days of Party B and its employees (hereinafter referred to as "workers").

4. Be responsible for providing technical guidance, civilization and safety education to Party B and its employees;

5. Be responsible for providing Party B with production materials, production sites, production water and electricity (the expenses shall be borne by Party B).

6. Provide complete construction drawings and be responsible for drawing disclosure.

Verb (abbreviation of verb) Rights and obligations of Party B.

1. Party B shall cooperate with and obey the management of Party A's project department, obey the coordination of field personnel appointed by Party A, and have the obligation to cooperate with the management of supervision, design unit and quality and safety supervision department;

2. Party B has the responsibility to regularly educate its employees about safe production and civilized construction; Be directly responsible for the safety of the workers they employ;

3. Be responsible for training the workers employed by them on the site equipment operation procedures and production technology, and ensure the implementation of the operation procedures and production technology;

4. Party B is responsible for handling industrial injury insurance and personal accident insurance for its employees;

5. Party B shall provide Party A with the list of laborers and a copy of ID card (submitted to the original for verification) two days before the laborers enter the production site, as the basis for Party A to pay the basic labor fee;

Payment method of intransitive verbs:

(1) Pay the actual attendance service fee before the date of 10 every month;

(2) After Party A pays 80% of the contract labor costs, it will not pay any more labor costs. After the acceptance of the project and Party A, the project price shall be paid to 95% of the settlement price within 30 days after the settlement is confirmed by both parties, and 5% shall be kept as the quality guarantee. The warranty period is 2 years, subject to the completion report.

Seven. Dispute settlement clause

Any dispute arising from the performance of this agreement between Party A and Party B shall be settled through negotiation as soon as possible. If negotiation fails, either party shall bring a lawsuit to the court with jurisdiction where Party A is located.

Eight, other terms:

1. This agreement and its performance do not constitute proof of the labor relationship between Party A and Party B's workers. Party B directly manages the workers under the guidance of Party A, and all disputes arising from wage payment and personal losses of workers shall be handled by Party B itself. If Party A bears relevant responsibilities directly or indirectly, Party A has the right to recover from Party B;

2. This agreement is made in duplicate, one for Party A and one for Party B. It shall come into effect as of the date of signature by both parties or authorized representatives, and shall automatically become invalid after the settlement of labor services provided by Party B is completed. The annex to this agreement includes a copy of the ID card of Party B's representative.

Party A (seal): _ _ _ _ _ _ _ _ _ _ Party B: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

Representative (signature): _ _ _ _ _ _ _ _ _ ID number: _ _ _ _ _ _ _ _ _ _ _ _ ID number: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

_ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _.

4. General Edition of Engineering Labor Contract Model

Party A: legal representative or entrusted agent of xxxxxx: _ _ _ _ _ _ _ _ _ _ _ _

Mailing address: __xxxx

Postal code: _ _

Telephone _ _

Party B: Name and gender

Resident ID number _ _ _ _ _ _ _ _ _ _ Date of birth _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

Home address: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

Article 1 This Agreement shall come into force on _ _ _ _ _ _ _ _ _ _ _ _ _ _.

Article 2 The contents and requirements of the services undertaken by Party B are as follows:

Article 3 Party B shall provide labor services in the following ways:

Article 4 The labor remuneration paid by Party A to Party B is RMB 65,438 yuan+0,000 yuan (in words: one thousand yuan only).

Article 5 Party B shall provide services to Party A in accordance with the service contents, requirements and methods agreed in Articles 2 and 3 of this Agreement, and Party B is also willing to undertake the agreed services.

Article 6 Party B has the obligation to keep Party A's business secrets. The business secrets that Party B is obliged to protect mainly include:

Article 7 The standard and method for Party A to pay Party B labor remuneration: _ _ bank transfer or Alipay _ _.

Article 8 Party B shall pay personal income tax of RMB 40 yuan (in words: forty yuan only), which shall be withheld by Party A on its behalf.

Article 9 This Agreement shall be terminated under any of the following circumstances:

1. Agreement expires;

2. Both parties reach an agreement on the dissolution of this Agreement;

Three. Party B is unable to perform its obligations under this Agreement due to health reasons.

4. The contract is terminated due to force majeure.

Article 10 If Party A and Party B unilaterally terminate this Agreement, they only need to notify each other one week in advance.

Article 11 After the termination and dissolution of this Agreement, Party B shall hand over relevant work to Party A within one week, and make a written explanation. If losses are caused to Party A, Party B shall compensate.

Article 12 If this Agreement is terminated or dissolved according to Articles 10 and 11 of this Agreement, both parties shall not pay liquidated damages to each other.

Article 13 Any dispute arising from or related to this Agreement shall be submitted to the Beijing Municipal People's Court for arbitration. The arbitral award is final and binding on both parties.

Article 14 The mailing addresses of Party A and Party B in this contract are the fixed mailing addresses of both parties. If there is any dispute between the two parties during the performance of this agreement, even if arbitration is involved, this address will be the legal address of both parties. If one party's mailing address changes, it shall immediately notify the other party in writing, otherwise, the party at fault shall be responsible for the communication obstacles between the two parties.

Article 15 This contract is made in duplicate, with each party holding one copy.

Party A (seal): _ _ _ _ _ _ _ _ _ _ Party B: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

Representative (signature): _ _ _ _ _ _ _ _ _ ID number: _ _ _ _ _ _ _ _ _ _ _ _ ID number: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

_ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _.

5. General Edition of Engineering Labor Contract Model

Employer: _ _ _ _ _ _ _ _ _ _ _ _ Contractor: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

Article 1: Project Overview

Work content: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _.

Project name: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _.

Project scope: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _.

Article 2: Operators

Article 3: Term of Contract

Risk warning:

A clear agreement on the project duration is conducive to ensuring the project progress and is a necessary condition to ensure the normal progress of the project. In addition, if the contractor fails to pay the corresponding labor remuneration according to the agreed time, the labor employer may also require the contractor to bear the corresponding liability for breach of contract.

In addition, in the litigation involving the construction period, the legal consequences of the delay in the construction period are different for different reasons, so the time agreement for the labor contractor to be paid labor remuneration will also change. During the performance of the project contract, the labor contractor shall make a written determination on the possible delays in the construction period, such as increasing construction projects, increasing workload and providing raw materials, so as to avoid unfounded lawsuits in the future.

The commencement date is _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _.

Article 4: Contract Price

1. The contract price is _ _ _ _ _ _ (RMB), in words: _ _ _ _ _ _ _.

2. Principles for determining the contract price (tick "√" before the confirmation method):

After bidding or no bidding procedure, the contractor and the contractor agree to confirm through consultation:

(1) The contract price is fixed and will not be adjusted within the agreed risk range.

(2) Estimate the quota according to the construction budget in _ _ _ _ or _ _ _ _ _ _.

(3) The unit price of odd jobs outside the quota is _ _ _ _ _ yuan/man-day. (Subject to the actual occurrence and written visa information)

Article 5: Settlement and Payment of Contract Price

1, settlement and final accounts:

(1) The Employer shall provide the contractor with the engineering construction drawing or bill of quantities, and the contractor shall prepare the construction budget according to the above written materials according to the terms of this contract.

(2) According to the construction task book issued by the Employer or the instructions of the on-site person in charge, the contractor arranges the operators to finish the work, obtains effective written visa documents, and prepares the artificial settlement book.

(3) Effective monthly workload settlement data, written consultation changes, and on-site sign-off data, etc.

2. Settlement and final accounts of the contract price:

(1) The Employer shall verify and confirm the quantities completed by the Contractor on _ _ every month, and * * * perform the written settlement procedures.

(2) Within _ _ _ _ days after the completion of the project, the contractor shall submit the complete final accounts to the Employer, and the Employer shall verify and confirm them within 28 days after receiving the final accounts, and go through the formalities for the final accounts of the subcontracted project.

3. Payment of contract price:

(1) The contract price shall be paid by installments: RMB _ _ _ _ _ _ _ _ _ _ _

Article 6: Handling of Safe Construction, Major Casualty Accidents and Other Safety Accidents

1. Safe construction: The employer and the contractor must implement the laws, regulations and rules on safe production promulgated and implemented by the state, government and industry authorities, and organize the construction in strict accordance with safety standards.

2, heavy casualties and other safety accidents:

(1) In the event of a safety accident such as heavy casualties, both parties shall take emergency measures to prevent the situation from getting worse, and make every effort to rescue the injured and protect the scene of the accident. If it is necessary to move the field equipment to rescue the injured, a written record should be made or photos taken.

(2) According to the relevant regulations, the employer and the contractor should distinguish the responsibilities, and the party responsible for the accident should bear the corresponding responsibilities. When the employer and the contractor have disputes over the responsibility of the accident, they shall be handled according to the determination of the relevant government departments.

Article 7: Project Quality, Acceptance and Warranty

Risk warning: the imputation of substandard project quality

If the project quality fails to meet the standards agreed in the contract due to the contractor's reasons, the contractor shall bear the increased costs and/or delayed construction period, and pay the corresponding profits.

If the project quality fails to meet the standards agreed in the contract due to the contractor, the Employer has the right to require the contractor to rework until the project quality reaches the standards agreed in the contract, and the contractor shall bear the increased expenses and/or delayed construction period.

1, engineering quality should meet the requirements of design drawings and agreed standards and quality objectives. If the drawings and instructions of the Employer are different or inconsistent with the national and local government's construction acceptance specifications and standards, the Contractor shall, after obtaining the written approval of the Employer, take the higher quality requirements as the construction basis.

2. The contractor must organize the construction according to the quality inspection standards, construction acceptance specifications and construction drawings stipulated by the state. If design errors are found in the construction process, they must be raised to the owner immediately, and the construction can be continued only after the negotiation procedure is orally changed. The employer shall make economic compensation for the slowdown caused by the employer; In case of slowdown caused by the contractor, the construction period shall not be postponed, and the expenses incurred shall be borne by the contractor.

3. The acceptance of subcontracted projects is based on the construction acceptance specifications, quality inspection standards and construction drawings issued by the state. Within 28 days after the completion of the subcontract works, the employer and the contractor shall go through the written acceptance procedures. If the acceptance is not completed within the time limit, and the Employer submits the subsequent construction or puts it into use, it shall be deemed as meeting the requirements of the contract and the project is completed.

Article 8: Delay in construction period

1. If the completion date is delayed due to the following reasons, the construction period will be postponed accordingly after confirmation by the owner's construction representative.

2. The contractor shall submit a written report to the employer's construction representative within 7 days after the above-mentioned situation occurs, and the employer shall give a written reply on extending the completion date and compensating for economic losses within 7 days. If the contractor fails to submit a written report within the time limit, it shall be deemed as giving up the right; If the employing unit fails to reply within the time limit and does not put forward suggestions for revision, it shall be deemed to acknowledge the fact.

3. If the project fails to be completed according to the contract time limit (including the extended time limit agreed in the contract) due to the above reasons, both parties shall reach an agreement.

Article 9: Civilized construction

1. The employer and the contractor shall strictly implement the Interim Provisions on Construction Site Management issued by the Municipal People's Government, strengthen scientific management and adhere to civilized construction.

2. The employer shall provide the contractor with standard construction conditions. If the Employer can't provide on-site accommodation or both parties agree that the Contractor will solve the accommodation by himself, the Employer will compensate according to the standard.

Article 10: supply of materials and machinery

Risk warning: obligations and responsibilities of purchasing materials and engineering equipment.

When the materials and engineering equipment purchased by the contractor do not meet the requirements of the design or relevant standards, the contractor shall, within a reasonable period required by the supervisor, transport the materials and engineering equipment that do not meet the requirements of the design or relevant standards out of the construction site, and re-purchase the materials and engineering equipment that meet the requirements, and the contractor shall bear the increased expenses and/or delayed construction period.

If the specifications, quantity or quality of materials and engineering equipment provided by the Employer do not conform to the contract, or the delivery date is delayed or the delivery place is changed due to the Employer's reasons, it shall be handled according to the provisions of the Employer's breach of contract.

1. Tools provided by the contractor must be brought to the site. The mechanical equipment and protective equipment provided by the Employer shall be purchased by the Employer and supplied to the construction site (within 400 meters).

2, the contractor shall abide by and implement the provisions of the employer's materials, machines and tools recipients, recipients of materials, machines and tools with the employer * * * inventory, to fulfill the written collar, also procedures, borrow the employer's machines and tools, should be used in strict accordance with the operating procedures, strengthen maintenance.

Article 1 1: Rights and obligations of the employer

1, responsible for providing the construction site with construction conditions such as site, roads, water and electricity, and for organizing and coordinating the construction and disclosing the technology, quality, safety and site capacity.

2, responsible for _ _ _ _ _ _ _ _ _ _ _ _

3. Organize the construction inspection and acceptance, and supervise the contractor's project progress, project quality, production safety and construction according to the drawings, material requisition and administrative affairs.

4, responsible for solving the technical problems existing or occurring in the construction.

Article 12: rights and obligations of the contractor

1. The contractor must carefully examine the workers who have established labor relations with them to ensure the political quality, physical quality and technical level of the personnel. The age of workers shall not be less than 18 years old and shall not exceed 60 years old.

2. The contractor shall register its operators (name, gender, age, native place, type of work, level, work permit number and ID number shall be indicated) as an annex to this contract.

3, in the process of construction and production, the contractor must ensure that the personnel are relatively stable, can't change the filing personnel at will, and the turnover rate does not exceed _ _%, subject to the overall arrangement of the employer and unified mobilization.

4. If the Employer cannot guarantee continuous production for some reason, the contractor may temporarily adjust the team without affecting the production task of the Employer, and the adjusted personnel shall send a written notice to the Employer and go through the change procedures.

Article 13: Liability for breach of contract

Risk warning: define the liability for breach of contract.

When signing a contract, both parties should think about the possible breach of contract and stipulate the corresponding punishment measures in the contract. By defining the responsibilities that need to be borne in case of breach of contract, all parties can be urged to truly fulfill their obligations. Once the contract is breached, there is evidence to follow.

1, the employer's liability for breach of contract:

(1) In case of shutdown or slowdown due to the Employer, the Contractor shall be compensated for the losses according to the actual situation. Shutdown and slowdown should be negotiated in writing and used as the basis for final accounts. If the employer cannot continue to perform the contract due to insufficient tasks or reasons, both parties may terminate the contract in advance after consultation.

(2) The Employer shall bear the economic losses and related responsibilities for the engineering quality problems caused by the command errors of the Employer's construction personnel.

(3) If the Employer fails to pay the labor cost or the balance of the final settlement price beyond the agreed payment time, the Contractor may issue a notice to the Employer to demand payment. If the employer fails to pay as required after receiving the notice from the contractor, it may negotiate with the contractor to sign a deferred payment agreement. With the consent of the contractor, the employer may postpone the payment of the labor fee or the balance of the final settlement price that has not been paid according to the contract. If both parties fail to reach an agreement on deferred payment, the contractor has the right to notify the employer in writing of the reasons, evacuate its personnel, and recover the arrears and losses according to law.

2, the contractor's liability for breach of contract:

(1) If the construction period of the Employer is delayed or the project quality is seriously unqualified due to the contractor, the Employer may terminate the contract and require the Contractor to withdraw from the construction site within _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

(2) If the contractor fails to enter the site according to the construction team selected by the Employer, the Employer has the right to require the contractor to make replacement and adjustment; If the contractor can't make adjustments, the employer has the right to temporarily not arrange the construction task (the risk shall be borne by the contractor) and notify the contractor in writing until the contract is terminated.

(3) The quality accidents and delays caused by the contractor shall be borne by the contractor.

Article 14: Settlement of Contract Disputes

In case of any dispute during the performance of this contract, both parties shall first settle it through consultation. If negotiation fails, you can apply to the relevant departments for mediation. If the parties are unwilling to settle or mediate, or the settlement or mediation fails, they may bring a lawsuit to the people's court of _ _ _ _ _.

Article 15: Entry into force and termination of the contract

This contract shall come into effect after being signed and sealed by the legal representatives or entrusted agents of both parties. The legal representative shall show his identity certificate, and the entrusted agent shall show his entrustment certificate.

This contract shall be terminated after the subcontracting work is completed and the project is completed and settled.

Article 16: The original of this contract is in duplicate, with the same legal effect. Each party holds _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _.

Employer: _ _ _ _ _ _ _ _ _ _ Contractor: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

_ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _.