Processing Contract 1 Party A: (Ordering Party)
Party B: (Contractor)
According to the relevant provisions of the Contract Law of People's Republic of China (PRC) on ordering clothes from Party B, this contract was reached through friendly negotiation between both parties. ..
I. Fixed crops
Clothing name:
Style:
Structure name:
Unit of measurement:
Unit price:
Amount:
Remarks:
Second, the quality standards and requirements of fabrics and accessories
Three, clothing style characteristics and production requirements
Four, clothing quality standards and acceptance methods
V. Measuring time
Within days from the effective date of this contract, Party B shall send personnel to Party A for measurement within the agreed time.
Six, supporting and packaging requirements
Seven. Settlement method and payment term
Eight. Time, place and method of delivery
Party B shall deliver the goods within _ _ _ _ days after the measurement is completed. The place of delivery is Party A's office. The freight shall be borne by Party B. ..
Nine. opposition
If Party A has any objection to the quantity, quality and style of the clothes submitted by Party B, it shall raise it within 15 days from the date of receiving the clothes. Party B shall give a reply and propose a solution within 10 days.
X. liability for breach of contract
1. In case of overdue payment, Party A shall pay liquidated damages at the rate of three ten thousandths of the total contract amount per day.
2. In case of late delivery, Party B shall pay a penalty of three ten thousandths of the total contract amount per day.
3. If Party B fails to complete the measurement work according to the agreed time due to Party A's reasons, the delivery time of Party B will be postponed.
XI。 Matters not covered in this contract shall be settled by both parties through consultation. Any dispute arising from the performance of this contract can be brought to court by both parties.
Twelve. This Contract is signed on _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _
Party A:
_ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _
Party B:
_ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _
Contract II: Party A (orderer): _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _
Party B (contractor): _ _ _ _ _ _ _ _ _ _ _
With regard to the business that Party A entrusts Party B to process and manufacture plastic steel windows, in order to clarify the rights, obligations and economic responsibilities of both parties in the contract and ensure the full performance of the contract, according to the Contract Law of People's Republic of China (PRC) and relevant regulations, both parties have reached the following terms through equal consultation for common compliance.
Article 1 Determine the name, quantity, specifications, quality and price of crops.
Note: The unit price per square meter includes all installation costs of window frames, glass, screens and hardware. The price is a one-time package price, including tax. When the buyer continues to order, it shall send a plan notice to the supplier days in advance to inform Party B. ..
Article 2 Contract Method and Provision of Materials
2. 1 Contract method: Party B shall undertake the work and materials, and all materials shall be provided by Party B according to the contract. Responsible for production, installation and transportation to the construction and installation site;
2.2 The contract price includes: fabrication, installation, transportation, coordination, water and electricity, etc.
2.3 Material standard: profile (manufacturer designated by Party A), mm anticorrosive steel lining, high-quality hardware and other accessories, casement windows are hidden screens, and sliding windows are ordinary screens.
2.4 Raw materials such as plastic steel used by Party B for processing must have factory certificates. If inspection is required, the inspection certificate shall be provided to Party A as quality data ... It is forbidden to use unqualified products and fake and inferior products. If Party B returns the goods unconditionally, Party B will return the goods again.
Article 3 Scope of Contract
3. 1 scope of processing contracted by party b: all plastic steel windows in this project.
3.2 Project Location: _ _ _ _ _ _ _ _ _ _ _ _ _ _
Article 4 Calculation, settlement and payment methods of contract price
4. 1 Calculation method: each side of the hole area is reduced _ _ _ _ _ _ _ _ _ _ _ _ cm (against the wall). If there is any change, the settlement shall be made in writing according to the size change.
4.2 After the signing of this contract, auxiliary materials shall be purchased by Party B, but samples must be provided, and they can be used in large quantities only after Party A agrees.
4.3 Payment method: Pay by unit project. If the window frame is installed and accepted by the relevant departments, the completed quantities shall be paid. After the window sash is installed and accepted by the relevant departments, it will be paid to the total settlement price after the project is completed and accepted by Party A, the supervision company, the construction unit and the fire department, and the remaining% will be used as the quality deposit, which will be paid after many years without quality problems.
4.4 According to each payment node, Party B will submit the construction task book to the accounting department of the company for accounting after it is signed by relevant personnel of Party A on time, and pay the project payment accordingly.
Article 5 Contract Price and Remuneration: The contract price shall be calculated by * * * *, and shall be settled in real terms.
Article 6 Processing, Manufacturing and Installation Requirements
6. 1 Party A shall provide Party B with complete door and window tables, relevant materials and construction line 50 in time after the signing of this contract, and the specific construction dimensions shall be measured by Party B on site, with Party A's cooperation.
6.2 After Party B enters the site, Party A shall cooperate to connect the power supply and install the electricity meter, and Party B shall bear the electricity fee.
6.3 Party B must design the window in strict accordance with the requirements of Party A's drawings and instructions, and submit samples, which can be produced only after being reviewed and signed by Party A. The finished products can be installed only after passing the on-site sampling inspection by Party A's supervision.
Validity and number of copies of the contract This contract is made in triplicate, two for Party A and one for Party B, and shall come into effect after being signed and sealed by both parties.
Party A: _ _ _ _ _ _ (seal) Party B: _ _ _ _ _ _ (seal)
The place of signing this contract is: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _
Date of signature: _ _ _ _ _ _ _ _ _ _ _ _
Contract 3 Processing Agent: _ _ _ _ _ _ (Party A)
Contractor: _ _ _ _ _ _ _ (Party B)
1. Processing item, product name, specification _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _.
Product name, specification, unit quantity, unit price _ _ _ _ _ _ _ _ (yuan), total price _ _ _ _ _ _ _ (yuan), delivery date, first quarter, second quarter, galvanized heald _ _ _ _ _ _ _ _ _ _ _ _ _ _.
2, quality standards:
Party B shall process according to the technical requirements and quality standards specified in the drawings provided by Party A. The processed parts provided by Party A are allowed to be damaged by _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _
3, raw material supply:
Zinc blocks for processing shall be provided by Party A. ..
4. Delivery method:
Party B shall be responsible for the round-trip transportation, and the freight shall be borne by Party B. ..
5, quality acceptance method:
After the processing is completed, Party A shall accept it according to the quality standard.
6. Settlement method:
____________________。
7. Liability for breach of contract:
Party A entrusts Party B to process zinc plating and quenching. Party B shall complete the project on the specified date; In case of overdue, Party B shall bear the economic losses of Party A and pay a penalty of 0.000 of the total value of processed products every day. If Party A fails to deliver the processed products to Party B at the specified time and quantity, thus causing the shutdown loss of Party B, it shall compensate for the actual loss.
Party A: _ _ _ _ _ _ _ _ _
Legal Representative: (Seal) _ _ _ _ _ _
Address: _ _ _ _ _ _ _ _ _ _ _ _
Bank account number: _ _ _ _ _ _ _ _ _ _ _
Party B: _ _ _ _ _ _ _ _ _ _ _
Legal Representative: (Seal) _ _ _ _ _ _
Address: _ _ _ _ _ _ _ _ _ _ _ _
Bank account number: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _
_ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _
Processing Contract 4 Party A:
Party B:
Through negotiation between Party A and Party B, Party A entrusts Party B to process according to the specifications and models provided by it, and the raw materials are provided by.
1. Product name, model, quantity and amount:
Total amount: RMB _ _ _ _ _
Total contract price: RMB _ _ _ _ _ _ (in words: _ _ _ _ _)
2. Quality requirements: The construction in strict accordance with the drawings provided by Party A is qualified.
3. Place and method of delivery (delivery): self-delivery.
Four. Delivery time: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _
Verb (abbreviation for verb) Terms of payment and settlement period:
Liability for breach of contract of intransitive verb: Party B shall not produce if Party A fails to pay in time; If Party B fails to deliver the goods on time, it shall bear the losses for breach of contract.
Seven. Ways to resolve contract disputes: both parties shall negotiate or submit to Xi Arbitration Commission for settlement.
8. This contract shall come into effect as of the date of signature by both parties, and shall automatically become invalid after payment is settled.
9. Party B can handle the information needed by Party A according to the fax file provided by Party A, and the fax file has the same legal effect as the original.
X this contract is made in duplicate, one for each party. Have the same legal effect.
Party A (official seal): _ _ _ _ _ _
Party B (official seal): _ _ _ _ _ _
Legal representative (signature): _ _ _ _ _ _
Legal representative (signature): _ _ _ _ _ _
_ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _
_ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _
Name of the fifth unit of the processing contract: (Party A) _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _
Company name: (Party B) _ _ _ _ _ _
Rule number one. Project overview
1. Name of construction site: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _
2. Site location: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _.
3. Door and window area: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _
4. The project time is _ _ _ _ _ days (the construction period is postponed due to irresistible factors such as wind and rain and power failure).
5. The unit price of the project: _ _ _ _ _ _ yuan, the estimated engineering quantity is _ _ _ _ _, and the total project cost is _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _
6. Safe construction: Party B shall carry out safe construction. In case of any accident, Party B shall bear all expenses, which has nothing to do with Party A. ..
Article 2. Payment method:
1. Party A shall pay Party B _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _
2. Party A shall pay Party B _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _
3. Party A shall pay _ _ _ _ _ _ _ _ to Party B.
4. After the installation is accepted and signed by Party A, Party A shall pay the total project price of _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _.
Article 3, doors and windows requirements:
_________________________________________
___________________________________________________________
___________________________________________________________
Article 4, quality requirements:
1. Party B shall construct according to the design drawings. If the design change is notified to the design unit, the construction shall be carried out in strict accordance with the relevant national construction specifications. In case of non-compliance with the construction specifications, Party B shall be responsible for the losses.
2. In the process of construction, Party A proposes to change the original design scheme, and some expenses for the change shall be signed separately.
Article 5: Matters not covered in this contract shall be settled by both parties through consultation.
Article 6: This contract is made in triplicate, all of which have legal effect.
Party A (seal): _ _ _ _ _ _ Party B (seal): _ _ _ _ _ _ _ _ _ _
Address: _ _ _ _ _ _ _ _ _ _ _ _ Address: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _
Legal representative: _ _ _ _ _ _ _ _ Legal representative: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _
Phone number: _ _ _ _ _ _ _ _ _ Phone number: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _
Mobile: _ _ _ _ _ _ _ _ _ _ Mobile: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _
Date: _ _ _ _ _ _ _ _ _ _ _ _ Date: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _
Party A _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ (hereinafter referred to as Party A)
Party B _ _ _ _ _ _ _ (hereinafter referred to as Party B)
Through friendly negotiation, both parties have reached the following agreement on the processing of _ _ _ _ _ _ _ _ _ aluminum alloy doors and windows.
I. Quantity and specifications
1, the products customized by Party A are _ _ _ _ _ _ _ series aluminum, the thickness of aluminum is _ _ _ _ mm, the color of sprayed aluminum is _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _
2. The unit price is _ _ _ _ _ Yuan/m2. (The specific specifications and dimensions are subject to the drawings, excluding tax)
Second, quality.
1, Party B will strictly follow the relevant national regulations and the technical quality requirements of the enterprise.
2. The door and window products produced by Party B shall be guaranteed for one year. During the warranty period, all parts have not been repaired or replaced except for man-made damage factors, and will be repaired after one year.
Third, the approach and installation period
1 After the establishment of this sales contract, confirm the number and size of drawings, and Party B will start to install the wall after receiving Party A's commencement.
2. If Party A fails to provide Party B's operation surface in real time, Party A agrees to postpone it.
Four. mode of payment
1, Party A shall pay Party B _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _
2. The settlement area shall be subject to the actual drawing size.
Verb (abbreviation of verb) Responsibilities and scope of work of both parties.
1 During the construction process, Party B's construction personnel must take strict safety protection measures and enter the construction site, and Party B must abide by and obey the construction management of the general contractor.
2. Party B shall manufacture and install doors and windows according to size of the hole approved and confirmed by Party A..
Other matters of intransitive verbs
This contract is made in duplicate, one for each party, and shall come into effect after being signed or sealed by the representatives of both parties. If there are any matters not covered, both parties shall determine them in the form of work contact sheet or negotiate separately.
Party A (official seal): _ _ _ _ _ _ _ _ _ _ Party B (official seal): _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _
Legal representative (signature): _ _ _ _ _ _ Legal representative (signature): _ _ _ _ _ _
_ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _.
Ordering party of processing contract 7: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _
Contractor: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _
According to the Contract Law of People's Republic of China (PRC) and relevant laws and regulations, and following the principles of fairness, honesty and credibility, the ordering party and the contractor have reached the following agreement through consultation:
Article 1 Determine crops, quantities, specifications and remuneration.
Determine the crop name, specifications/models and quality requirements/
Technical standard measurement
Delivery time reward per unit quantity
Pricing method of fixed remuneration: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _
Total (in words): RMB _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _.
Article 2 The ordering party shall pay (advance payment/deposit) RMB _ _ _ yuan to the contractor within _ _ _ days after signing the contract, and the remaining payment methods are as follows.
Article 3 Materials provided by the hirer
Material name specification/model quality standard measurement
Supply time per unit quantity
The contractor shall inspect the materials provided by the ordering party after receiving them, and raise a written objection to the ordering party for the materials that do not meet the agreed standards within 3 days. If the contractor fails to raise a written objection within the time limit, it shall be deemed that the materials provided by the ordering party conform to the contract.
Article 4 The ordering party shall, before _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _
When the contractor finds that the drawings and technical requirements provided by the ordering party are unreasonable, it shall raise a written objection to the ordering party within 3 days after receiving them.
Article 5 The ordering party has the right to supervise and inspect the materials and finished products used by the contractor, and require the contractor to replace, repair and rework the materials and finished products that are not in conformity with the agreement, and the expenses shall be borne by the contractor.
Article 6 Without the written consent of the ordering party, the contractor shall not hand over the crops to a third party for completion, otherwise the contractor shall have the right to terminate the contract.
Article 7 The contractor shall deliver crops, corresponding technical data and quality certification documents at the agreed time and place. The delivery place is _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _.
The transportation, loading and unloading of crops and expenses shall be borne by _ _ _ _ _.
If the crops need to be installed and debugged, the contractor shall complete the installation and debugging at the designated place according to the requirements of the ordering party and deliver them through the acceptance party. The contractor agrees to waive the lien.
Article 8 The ordering party shall timely check and accept the crops delivered by the contractor. The inspection standards, methods and time limits of crops are as follows:
Article 9 The contractor shall undertake the warranty responsibility for the quality of crops, and the warranty period shall be from MM DD YY to MM DD YY. During the quality guarantee period, the ordering party shall reserve the quality guarantee fund at the rate of _ _% of the total contract price, which will be returned after the quality guarantee period without any quality problems.
If the crops have quality problems during the warranty period, the contractor shall repair and redo them in time, and compensate all losses caused by the given crops (including but not limited to shutdown losses and economic responsibilities to third parties). If the contractor fails to repair the replanted crops in time according to the requirements of the ordering party, the ordering party has the right to repair the crops by itself, and the cost will be directly deducted from the reserved quality warranty fund, and the ordering party has the right to continue to claim compensation from the contractor for the insufficient part.
Article 10 Liability for breach of contract:
1. If the contractor fails to deliver the ordered crops, and the quality, quantity, specifications, models, colors and packaging methods of the ordered crops do not meet the standards agreed in the contract, the contractor will breach the contract; Where the hirer fails to pay the remuneration, it shall be deemed that the hirer has breached the contract.
2. The hirer suffers losses due to the breach of contract by the hirer or bears economic responsibilities to a third party (including but not limited to shutdown losses, liabilities for breach of contract to the construction unit and subcontractors, etc.). ), the ordering party shall compensate the ordering party for all economic losses.
3. If the quality, quantity, specifications, models, colors and packaging methods of the contracted crops do not meet the standards stipulated in the contract, the ordering party has the right to reject the contracted crops or refuse to pay remuneration; The contractor shall be responsible for maintaining and replanting crops according to the standards agreed in the contract. If the contractor fails to maintain and replant crops according to the standards agreed in the contract as required by the ordering party, the ordering party has the right to require it to continue to perform or terminate the contract. If the ordering party terminates the contract, the contractor shall also pay the ordering party a penalty of 3% of the total contract price. If it is not enough to make up for the loss of the ordering party, the contractor shall continue to make compensation.
Article 11 Any dispute arising from the performance of this contract shall be settled by both parties through consultation. If negotiation fails, a lawsuit shall be brought to the people's court where the ordering party is located according to law.
Article 12 This Contract is concluded in the form of _ _ _ _ _ _ _ _ _ _ _ _.
Article 13 Supplementary Articles: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _
The orderer: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _
Domicile: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _
Phone number: _ _ _ _ _ _ _ Phone number: _ _ _ _ _ _ _ _ _ _ _ _
Authorized Agent: _ _ _ _ _ _ _ _ _ _ _ _ Authorized Agent: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _
_ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _.
Processing Contract 8 Party A: _ _ _ _ _ _ _
Party B: _ _ _ _ _ _ _ _ _
Party A promises _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _
I. Style number or product name of the processed clothing: _ _ _ _ _ _ _.
2. Number of processed pieces: _ _ _ _ _ _, delivery date _ _.
3. Unit price of processing fee (including tax): RMB/piece, with a total amount of RMB.
Four, processing standards and quality
1, processed and manufactured according to the sample clothes and technical requirements provided by the entrusting party or Party A..
2. During the processing of Party B, Party A or the entrusting party has the right to supervise the processing quality, and must obey the quality requirements put forward by the merchandiser sent by Party A or the entrusting party, and make changes or repairs according to the technical requirements of the merchandiser.
3. Delivered after being accepted by Party A or the entrusting party, but the final quality shall meet the quality standards of Party A or the entrusting party.
Verb (abbreviation of verb) payment terms
1. Settlement shall be made on the 20th day after Party A or the entrusting party makes a comprehensive inspection of the delivery date.
2. If there are special reasons, Party A and Party B shall solve them through negotiation.
Termination and change of intransitive verb contract
1. If Party B's processing quality still does not meet the requirements after rectification, Party A has the right to terminate this contract.
2. Party A may modify the processing contract entrusted by Party B according to Party B's processing and production schedule and order requirements.
Seven. Liability for breach of contract and compensation
1. In case of violation of Article 1 of Paragraph 5, Party B shall promptly return the processed clothing, semi-finished products, raw materials, auxiliary materials, etc. to Party A, and compensate Party A for its losses (including rework, repair and freight).
2. Party B's delay in delivery affects the normal performance of Party A's order contract, and Party B shall compensate Party A for all losses (including but not limited to Party A's breach of contract losses, air freight charges, litigation costs, attorney fees, etc.). ).
3. Party B deliberately delays or changes the settlement conditions, proposes to collect the loan and raises the price without authorization. Any action taken by Party A to complete the normal performance of the order contract does not mean that Party A has changed the contents of this contract. Party A has the right to claim compensation for Party B's breach of contract.
4. Party B agrees to the following compensation standards: the losses caused by Party A's failure to perform the order contract due to Party B's delay in delivery shall be determined according to the price agreed between Party A and the foreign party or ordering party, the breach of contract losses shall be determined according to the agreement between Party A and the foreign party or ordering party, other compensation shall be determined according to the amount in the foreign party or ordering party's claim letter, and the legal fees and attorney fees shall be determined according to the bill.
Eight. Matters not covered in this contract shall be settled by both parties through consultation, and disputes arising therefrom shall be decided by the court.
Nine. This contract is made in duplicate, one for each party. It will take effect immediately after signing.
Party A (official seal): _ _ _ _ _ _ _ _ _ Party B (official seal): _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _.
Legal representative (signature): _ _ _ _ _ Legal representative (signature): _ _ _ _ _
_ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _